Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Customer Requirements ▪ Seller shall comply with the applicable terms and conditions of any agreements between Buyer and Xxxxx’s Customer (the “Customer Purchase Orders”) pursuant to which Buyer agreed to sell to Buyer’s Customer products or assemblies which incorporate the goods provided by Seller hereunder. This provision specifically includes costs and obligations imposed by warranty programs instituted by the original equipment manufacturer that ultimately purchases Buyer’s products that incorporate the goods sold by Seller if applicable to Buyer under the terms of the Customer Purchase Order. ▪ If Buyer is not acting as a Tier One supplier, the defined term “Customer Purchase Order” shall also include the terms and conditions of the original equipment manufacturer that ultimately purchases Buyer’s product that incorporates the goods or services sold by Seller. ▪ Seller will be responsible to ascertain how the disclosed terms affect Seller’s performance under the Purchase Order. ▪ By written notice to Seller, Buyer may elect to disclose and have the provisions of the Customer’s Purchase Orders prevail over any term of the Purchase Order at any time.
Service Descriptions Available services for Transitional and Enhanced Supervision Services a. One (1) one-to-one meeting with the Contractor per week for case management services.
Additional Customer Terms If any additional ordinance, rule, or other local governmental authority requires additional contract language before a Customer can make a purchase under this Contract, the Customer is responsible for entering a separate agreement with the Contractor and incorporating the additional contract language therein.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Private Aircraft Mileage When an employee is authorized by his/her department, reimbursement for the use of the employee’s privately owned aircraft on State business shall be made at the rate of 50 cents per statute mile. Pilot qualifications and insurance requirements will be maintained in accordance with DPA rule 599.628.1 and the State Office of Risk and Insurance Management.
Service Level Agreements If a Service or a Plan includes a Service Level Agreement (SLA):
Task Order Funding Restrictions No unfunded TOs are allowed; TOs may be incrementally funded in accordance with FAR and other agency funding restrictions. The Contracting Officer for each order is responsible for closing out the contract action that they issue. Notification that a closeout of an order is complete must be provided to the Procuring Contracting Officer (the Basic Contract) once accomplished. The contractor shall work in partnership with the Government to closeout orders as soon as possible after they are physically complete by using the "Quick Closeout" procedures described in FAR 42.708 as much as practical. In accordance with section 1427(b) of Public Law 108-136 a protest is not authorized in connection with the issuance or proposed issuance of an individual TO except a protest on the grounds that the order increases the scope, period, or maximum value of the contract under which the order is issued; or a protest of an order valued in excess of $10 million. Protests of orders in excess of $10 million may only be filed with the Government Accountability Office, in accordance with the procedures at FAR 33.104. H138 INCORPORATION OF LABOR CATEGORIES AND MAXIMUM LABOR RATES (NOV 2009) Successful offerors Labor Categories and Maximum Labor Rates will be incorporated in the resultant contract as Attachment 5 in Section J and shall be valid for the life of the contract. Applicable to following Labor Hour Line Items: 0300, 1300, 2300, 3300, 4300 H139 SMALL BUSINESS GRADUATE TRANSITION (NOV 2009) This clause is being included in the Application Services Full and Open contracts for informational purposes only.