Cancellation by Licensee Liquidated Damages Force Majeure
Cancellation by Licensee Liquidated Damages Force Majeure Sample Clauses
Related to Cancellation by Licensee Liquidated Damages Force Majeure
Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.
Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Termination by Licensor Without Notice Licensee shall be deemed to be in default under this Agreement, and all rights granted herein shall automatically terminate without notice to Licensee, if Licensee becomes insolvent or makes a general assignment for the benefit of creditors; or if a petition in bankruptcy is filed by Licensee or against Licensee and not opposed by Licensee within sixty (60) days of such filing; or if Licensee is adjudicated as bankrupt or insolvent; or if a bill xx equity or other proceeding for the appointment of a receiver of Licensee or other custodian for Licensee's business or assets if filed and consented to by Licensee; or if a receiver or other permanent or temporary custodian of Licensee's assets or property, or any part thereof, is appointed by any court of competent jurisdiction; or if proceedings for a composition with creditors under any state or federal law should be instituted by or against Licensee; or if a material final judgment remains unsatisfied or of record for thirty (30) days or longer (unless supersedeas bond is filed); or if Licensee is dissolved; or if a suit to foreclose any lien or mortgage against real or personal property used in the operation of Licensee's business, the loss of which would have a material adverse effect on Licensee, is instituted against Licensee and not dismissed within thirty (30) days; or if execution is levied against Licensee's business or property, the loss of which would have a material adverse effect on Licensee; or if real or personal property of Licensee used in its business, the loss of which would have a material adverse effect on Licensee, shall be sold after levy thereupon by any sheriff, marshal, or constable; or if Licensee at any time ceases to operate or otherwise abandons its business or otherwise forfeits the right to do or transact business in any market(s) in the Territory; or if Licensee loses any government license required to engage in the Business or otherwise forfeits the right to do or transact business in one or more market(s), in which event Licensee's rights under this Agreement shall automatically terminate.
Damages for delay Subject to the provisions of Clause 12.4, if COD does not occur prior to the 91st day after the Scheduled Completion Date, unless the delay is on account of reasons solely attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority in a sum calculated at the rate of 0.1% (zero point one per cent) of the amount of Performance Security for delay of each day until COD is achieved.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination by Licensee Licensee, at its option, may terminate the Agreement by providing Licensor written notice of intent to terminate, which such termination effective will be ninety (90) days following receipt of such notice by Licensor.
