TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Cancellation by the Bank If (a) the right of the Borrower to make withdrawals from the Loan Account shall have been suspended with respect to any amount of the Loan for a continuous period of thirty days, or (b) at any time, the Bank determines, after consultation with the Borrower, that an amount of the Loan will not be required to finance the Project’s costs to be financed out of the proceeds of the Loan, or (c) at any time, the Bank determines, with respect to any contract to be financed out of the proceeds of the Loan, that corrupt or fraudulent practices were engaged in by representatives of the Borrower or of a beneficiary of the Loan during the procurement or the execution of such contract, without the Borrower having taken timely and appropriate action satisfactory to the Bank to remedy the situation, and establishes the amount of expenditures in respect of such contract which would otherwise have been eligible for financing out of the proceeds of the Loan, or (d) at any time, the Bank determines that the procurement of any contract to be financed out of the proceeds of the Loan is inconsistent with the procedures set forth or referred to in the Loan Agreement and establishes the amount of expenditures in respect of such contract which would otherwise have been eligible for financing out of the proceeds of the Loan, or (e) after the Closing Date, an amount of the Loan shall remain unwithdrawn from the Loan Account, or (f) the Bank shall have received notice from the Guarantor pursuant to Section 6.07 with respect to an amount of the Loan, the Bank may, by notice to the Borrower and the Guarantor, terminate the right of the Borrower to make withdrawals with respect to such amount. Upon the giving of such notice, such amount of the Loan shall be canceled.”
Termination by the Customer The Customer may terminate this Agreement by providing a written notice of termination to the Transfer Agent, specifying the date as of which this Agreement will terminate, which may be any date, including the date such written notice is provided, provided the circumstances described below giving rise to the termination right are continuing at the time of the Transfer Agent’s receipt of such written notice, if as a result of an Event Beyond Reasonable Control:
Termination by the Company This Agreement may be terminated by the Company at any time prior to the Effective Time:
Termination by the Service Provider 19.1 The Service Provider may by notice determine the employment of the Service Provider under this Agreement if the Service user is in default in respect of any one or more of the following:
Termination by the City 96.1. In addition to termination pursuant to any other article of this Contract, the Commissioner may, at any time, terminate this Contract by written notice to the Contractor. In the event of termination, the Contractor shall, upon receipt of such notice, unless otherwise directed by the Commissioner:
INDEMNIFICATION BY THE COMPETITIVE SUPPLIER Competitive Supplier shall indemnify, defend and hold harmless the Town and its officers, employees, officials, consultants, representatives and independent contractors (the “Indemnified Parties”), from and against any and all costs, liabilities, losses, judgments, damages, and expenses (including reasonable attorney’s fees), arising out of third-party claims, demands, causes of action, suits or other proceedings and incurred by, on behalf of or involving the Indemnified Parties to the extent such claims, demands, causes of action, suits or other proceedings arise from or in connection with (i) any material breach by Competitive Supplier of its obligations, covenants, representations or warranties contained in this Agreement, or (ii) Competitive Supplier’s actions or omissions in connection with its performance of this Agreement to the extent that such actions or omissions were negligent or not Commercially Reasonable. Competitive Supplier further agrees, if requested by the Town in writing to do so, to investigate, handle, respond to, and defend any such claim, demand, cause of action, suit or other proceeding at Competitive Supplier’s expense. The indemnification obligation of Competitive Supplier set forth above is in addition to and not in limitation or in lieu of any other rights and remedies available to the Town. This provision shall survive the expiration or earlier termination of this Agreement.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Modification by the Parties The Parties may by mutual agreement amend the Appendices to this Agreement, by a written instrument duly executed by all three of the Parties. Such an amendment shall become effective and a part of this Agreement upon satisfaction of all Applicable Laws and Regulations.
