Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.
NO BREACH OF CONTRACT The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
a) Terminate the Contract immediately, pursuant to Section K herein;
b) Afford the Contractor written notice of the breach and ten (10) calendar days or such shorter time that may be specified in this Contract within which to cure the breach;
c) Discontinue payment to the Contactor for and during the period in which the Contractor is in breach; and
d) Offset against any monies billed by the Contractor but yet unpaid by the County those monies disallowed pursuant to the above.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
BREACH OF CONTRACT TERMS The State reserves its right to all administrative, contractual, or legal remedies, including but not limited to suspension or termination of this contract, in instances where the Contractor or any of its subcontractors violate or breach any contract term. If the Contractor or any of its subcontractors violate or breach any contract term, they shall be subject to such sanctions and penalties as may be appropriate. The duties and obligations imposed by the contract documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law.
VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer’s default, breach of contract, or violation of contract terms shall be paid by Engineer.
Liabilities for Breach of Contract 11.1 The Parties agree and acknowledge that, if any Party (“Defaulting Party”) is materially in breach of any provision of this Agreement, or materially fails to perform or delays in performing any of its obligations hereunder, such breach, failure or delay shall constitute a default hereunder (the “Default”), and the non-defaulting Party shall be entitled to demand the Defaulting Party to rectify such Default or take remedial actions within a reasonable period of time. If the Defaulting Party fails to rectify such Default or take remedial actions within such reasonable period of time or ten (10) days from the receipt of the written notice from the non-defaulting Party requiring such rectification, the non-defaulting Party shall be entitled to make a decision at its sole discretion:
11.1.1 the WFOE shall be entitled to terminate this Agreement and claim from the Defaulting Party for damages if the Defaulting Party is any of the Existing Shareholders or the Company;
11.1.2 the non-defaulting Party shall be entitled to claim from the Defaulting Party for damages if the Defaulting party is the WFOE, provided that under no circumstances shall the Non-defaulting Party be entitled to terminate or rescind this Agreement unless otherwise provided by laws.
11.2 Notwithstanding anything to the contrary in this Agreement, this Article shall survive the termination of this Agreement.
TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.
Agreement Not in Breach of Other Instruments The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby and the fulfillment of the terms hereof will not result in a breach of any of the terms or provisions of, or constitute a default under, or conflict with, any agreement or other instrument to which the Buyer is a party or by which it is bound, the Certificate of Formation and the Partnership Agreement, any judgment, decree, order or award of any court, governmental body or arbitrator by which the Buyer is bound, or any law, rule or regulation applicable to the Buyer which would have a material effect on the transactions contemplated hereby.
Liability for Breach of Contract 1. Party A and Party B shall strictly perform the terms stipulated in the agreement. If one party breaches the contract, the breaching party shall bear the liability for breach of contract according to the contract.
2. If the product is delivered by Party A to Party B and Party B fails to raise any objection to the product quality within the acceptance period, Party B shall not apply for return or replacement; If the product quality problems caused by Party B due to Party B's reasons or the intervention of a third party, which are not caused by the product itself, and caused by Party B's failure to raise any objection within the time limit since the date of acceptance, Party A can repair and rework the products, and Party B shall bear the rework service fee, material fee, processing fee, labor wages and other expenses incurred by Party A;
3. If the payment is not made in advance and then delivered, the ownership of the goods stipulated in this agreement still belongs to Party A before Party B pays off the payment, and Party A has the right to take back the goods at any time. Meanwhile, before this, Party B shall properly keep the goods and ensure that they are intact. If there is any damage, Party B shall compensate Party A according to the price of the goods agreed in the agreement. If the amount is not enough to make up for the losses, it shall also compensate Party A for all losses.
4. If Party B violates the agreement or refuses to perform the cooperation content during the cooperation period of this agreement, and refuses to perform or even withdraws from the cooperation after being urged by Party A, Party A has the right not to return the initial fee paid by Party B as a security deposit; At the same time, Party B shall cooperate with Party A to return all cooperation materials such as cooperation project materials and trademark product authorization documents, and compensate all economic losses suffered by Party A;
5. If Party B violates this agreement and causes losses to Party A, all expenses (including but not limited to attorney fees, legal fees, arbitration fees, announcement fees, preservation fees, guarantee fees, appraisal fees and auction evaluation fees) incurred by Party A for safeguarding its own legitimate rights and interests shall be borne by Party B;
6. If Party B cancels or changes the order without authorization, it shall pay 20% of the order price as liquidated damages and compensate Party A for all losses such as stocking, labor and profit.
