We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Carried Forward R Sample Clauses

Carried Forward RSection No. 1 PRELIMINARIES AND GENERAL Bill No. 1 PRELIMINARIES 32 Adjustment to the contract value (clause 32) F:........................ V:........................ T:........................ Where prices are submitted by the contractor or nominated/selected subcontractors during the progress of the works in respect of contract instructions or in regard to a claim under the terms of the contract and notwithstanding the fact that such prices may be used in an interim payment certificate, there is to be no presumption of acceptance. Should the principal agent wish to accept any such prices prior to the issue of the final certificate, it will be in writing 33 Recovery of expense and loss (clause 33) F:........................ V:........................ T:........................ Item 34 Final account and final payment (clause 34) F:........................ V:........................ T:........................ The employer shall not pay any interest on amounts payable to the contractor for one hundred and forty two (142) days after the date of issue of the certificate of practical completion The employer shall, however, pay interest to the contractor at the rate stipulated in clause 34.11 on any amounts payable to the contractor more than one hundred and forty two (142) days after the date of issue of the certificate of practical completion but only for such period as the settlement of the final account is delayed by the non-performance of the principal agent or the employer or his agents. In evaluating non-performance for purposes of this clause a reasonable time shall be allowed to the employer or his agents to respond to any matter brought to his/their attention and which may affect the settlement of the final account Section No. 1 PRELIMINARIES AND GENERAL Bill No. 1 PRELIMINARIES
Carried Forward RSection No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6] F:............................. V:............................ T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ Item
Carried Forward RSection No. 1 Bill No. 1 Preliminaries
Carried Forward RSection No. 2 SFD2 Bill No. 1 EARTHWORKS 16 To bottom of concrate aprons m2 33 17 To bottoms and sides of trenches, etc. m2 52 SFD2 Bill No. 1 EARTHWORKS
Carried Forward RSection No. 1 Bill No. 1 PRELIMINARIES 8 Works risk (clause 8) F:..................... V:............................ T:............................ Item 9 Indemnities (clause 9)F:............................. V:............................ T:............................ Item 10 Works insurances (clause 10) F:............................. V:............................ T:............................ Item 11 Liability insurances (clause 11)F:............................. V:............................ T:............................ Item 12 Effecting insurance (clause 12)F:............................. V:............................ T:............................ Item 13 NO CLAUSE N/A 14 Security (clause 14)F:............................. V:............................ T:............................ Item 15 Preparation for and execution of the works (clause 15) F:............................. V:............................ T:............................ Item 16 Access to the works (clause 16)F:............................. V:............................ T:............................ Item 17 Contract instructions (clause 17)F:............................. V:............................ T:............................ Item 18 Setting out of the works (clause 18)F:.............................
Carried Forward RSection No. 1 Bill No. 1 PRELIMINARIES 45 Provisional bills of quantities (B2.2)F:............................. V:............................ T:............................ N/A 46 Availability of construction documentation (B2.3) F:............................. V:............................ T:............................ Item Item Item Item Item 51 Geotechnical investigation (B3.2)F:............................. V:............................ T:............................ Item 52 Inspection of the site (B3.3)F:............................. V:............................ T:............................ Item Existing premises occupied (B3.4)F:............................. V:............................ T:............................ Previous work - dimensional accuracy (B3.5)F:............................. V:............................ T:............................ Previous work - defects (B3.6)F:............................. V:............................ T:............................ 53 Services - known (B3.7)F:............................. V:............................ T:............................ Item 54 Services - unknown (B3.8)F:............................. V:............................ T:............................ Item 55 Protection of trees etc (B3.9)F:............................. V:............................ T:............................ Item
Carried Forward RSection No. 1 Bill No. 1 PRELIMINARIES 3 Documents (clause 3)F:............................. V:............................ T:............................ Item 4 Design responsibility (clause 4)F:............................. V:............................ T:............................ Item 5 Employer's agents (clause 5)F:.............................
Carried Forward RSection No. 1 Bill No. 1 PRELIMINARIES 76 Telecommunication facilities (B7.4) F:............................. V:............................ T:............................ Item 77 Ablution facilities (B7.5) F:............................. V:............................ T:............................ Item 78 Responsibility for prime cost amounts (B8.1)F:............................. V:............................ T:............................ Item