Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
Permitted License Uses and Restrictions (a) This Order Form Supplement allows you, as an authorized User under the Master Subscription Agreement, to use the Software on any Supported Device and on no other devices.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Restrictions on Use of Hazardous Substances Borrower will not cause or permit the presence, use, disposal, storage, or release of any Hazardous Substances, or threaten to release any Hazardous Substances, on or in the Property. Borrower will not do, nor allow anyone else to do, anything affecting the Property that: (i) violates Environmental Law; (ii) creates an Environmental Condition; or (iii) due to the presence, use, or release of a Hazardous Substance, creates a condition that adversely affects or could adversely affect the value of the Property. The preceding two sentences will not apply to the presence, use, or storage on the Property of small quantities of Hazardous Substances that are generally recognized to be appropriate to normal residential uses and to maintenance of the Property (including, but not limited to, hazardous substances in consumer products).
Federal Government End Use Provisions We provide the Services, including related software and technology, for ultimate federal government end use solely in accordance with the following: Government technical data and software rights related to the Services include only those rights customarily provided to the public as defined in this Agreement. This customary commercial license is provided in accordance with FAR 12.211 (Technical Data) and FAR 12.212 (Software) and, for Department of Defense transactions, DFAR 252.227-7015 (Technical Data – Commercial Items) and DFAR 227.7202-3 (Rights in Commercial Computer Software or Computer Software Documentation). If a government agency has a need for rights not granted under these terms, it must negotiate with Us to determine if there are acceptable terms for granting those rights, and a mutually acceptable written addendum specifically granting those rights must be included in any applicable agreement.
Landlord’s Right of Entry Landlord shall be allowed access to the premises, at any reasonable hour for the purpose of examining or exhibiting of same, and for making such repairs or alterations either as Landlord may deem necessary or appropriate or as Tenant may request. Tenants are not allowed to interfere with showings as this is a direct violation of your lease. In the City of Urbana Landlord will give tenants 24 hours notice. While not required in Champaign, Landlord will make reasonable effort to give tenant advance notice and may provide this notice through phone, email, verbal or posting notice. In cases of emergency repairs or due to complaints, Landlord may have to enter the premises with no formal notice.
Government’s Reservation of Rights The defendant understands that the United States expressly reserves the right in this case to:
No Restriction on Existing Examination and Investigative Authority That this Agreement shall in no way preclude any State Mortgage Regulator from exercising its examination or investigative authority authorized under the laws of the corresponding Participating State in the instance a determination is made wherein Respondent is found not to be adhering to the requirements of the Agreement, other than inadvertent and isolated errors that are promptly corrected by Respondent, or involving any unrelated matter not subject to the terms of this Agreement. The Parties agree that the failure of Respondent to comply with any term or condition of this Agreement with respect to a particular State shall be treated as a violation of an Order of the State and may be enforced as such. Moreover, Respondent acknowledges and agrees that this Agreement is only binding on the State Mortgage Regulators and not any other Local, State or Federal Agency, Department or Office.
GEOGRAPHIC AREA AND SECTOR SPECIFIC ALLOWANCES, CONDITIONS AND EXCEPTIONS The following allowances and conditions shall apply where relevant: Where the company does work which falls under the following headings, the company agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.