Certified Claim and Procedures Sample Clauses

Certified Claim and Procedures. 28.2.1 Contractor shall submit a written certified claim (“Certified Claim”) to Owner’s Contracting Officer signed by a duly authorized officer of Contractor. The Certified Claim at a minimum shall include: (a) the nature of the relief sought; (b) a narrative that fully explains the facts and circumstances underlying the Certified Claim, including the basis of Owner’s liability to Contractor; and (c) specific reference to or inclusion of all cost and schedule information (including as-built scheduling information), and other documentation fully supporting the Certified Claim seeking adjustment to the Contract Price or extension of time. 28.2.2 The Certified Claim shall contain a certification that, to the best of the certifier’s knowledge and belief: (a) the Certified Claim is made in good faith, and that the documents containing supporting information provided by Contractor are current, accurate, and complete as of the date of certification; (b) the amount of additional compensation and/or time of performance requested accurately reflects a reasonable adjustment in the added cost and time of performance to which Contractor reasonably believes it is entitled; and (c) that there is supporting cost and schedule information that reflects the Work performed as of the date of certification. For the purposes of this Section 28.2.2: (a) “current, accurate” means, as to each document, that it is: (i) the version of that document Contractor used in preparing and quantifying the Certified Claim; (ii) contains information Contractor used in preparing and quantifying the Certified Claim; and (iii) is a true copy of that document; and
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs

Related to Certified Claim and Procedures

  • Direct Claim Procedures In the event an Indemnified Party has a claim for indemnity under Section 7.02 against the Indemnifying Party that does not involve a Third Party Claim, the Indemnified Party agrees to give notice in writing of such claim to the Indemnifying Party. Such notice shall set forth in reasonable detail such claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party. If the Indemnifying Party does not notify the Indemnified Party within thirty (30) days following the receipt of a notice with respect to any such claim that the Indemnifying Party disputes its indemnity obligation to the Indemnified Party for any Losses with respect to such claim, such Losses shall be conclusively deemed a liability of the Indemnifying Party and the Indemnifying Party shall promptly pay to the Indemnified Party any and all Losses arising out of such claim. If the Indemnifying Party has timely disputed its indemnity obligation for any Losses with respect to such claim, the parties shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through such negotiations, such dispute shall be resolved by arbitration determined pursuant to Section 9.06.

  • Claim Procedures Claim forms or claim information as to the subject policy can be obtained by contacting Benmark, Inc. (800-544-6079). When the Named Fiduciary has a claim which may be covered under the provisions described in the insurance policy, they should contact the office named above, and they will either complete a claim form and forward it to an authorized representative of the Insurer or advise the named Fiduciary what further requirements are necessary. The Insurer will evaluate and make a decision as to payment. If the claim is payable, a benefit check will be issued in accordance with the terms of this Agreement. In the event that a claim is not eligible under the policy, the Insurer will notify the Named Fiduciary of the denial pursuant to the requirements under the terms of the policy. If the Named Fiduciary is dissatisfied with the denial of the claim and wishes to contest such claim denial, they should contact the office named above and they will assist in making an inquiry to the Insurer. All objections to the Insurer's actions should be in writing and submitted to the office named above for transmittal to the Insurer.

  • Claims and Review Procedures 6.1 For all claims other than Disability benefits:

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

  • Policy and Procedures If the resident leaves the facility due to hospitalization or a therapeutic leave, the facility shall not be obligated to hold the resident’s bed available until his or her return, unless prior arrangements have been made for a bed hold pursuant to the facility’s “Bed Reservation Policy and Procedure” and pursuant to applicable law. In the absence of a bed hold, the resident is not guaranteed readmission unless the resident is eligible for Medicaid and requires the services provided by the facility. However, the resident may be placed in any appropriate bed in a semi-private room in the facility at the time of his or her return from hospitalization or therapeutic leave provided a bed is available and the resident’s admission is appropriate and meets the readmission requirements of the facility.

  • DISPUTES RESOLUTION PROCEDURE 10.1 A major objective of this Agreement is to eliminate lost time and/or production arising out of disputes or grievances. The Parties to this Agreement are committed to complying with the terms of this procedure.

  • Dispute Procedures Contact Think with any questions concerning this Agreement or the Services by calling 0- 000-000-0000 (toll-free), Monday - Friday 8AM – 8PM ET (note these hours may change); by sending a letter to Think, P. O. Box 1288, Greens Farms, Connecticut 06838; or by sending an email to: xxxx@xxxxxxxxxxx.xxx. Think will refer all complaints and inquiries to a representative who will attempt to reach a mutually satisfactory resolution. If your complaint or inquiry is not resolved after you have called Think and/or the EDC, or for general information, you may contact the DPU for assistance toll-free at (000) 000-0000, or at XXXXxxxxxxx.Xxxxxxxxxx@xxxx.xxx, or by sending a letter to the DPU at: 0 Xxxxx Xxxxxxx, 0xx Xxxxx Xxxxxx, XX 00000. You have a right to make a formal or informal complaint to the DPU or any regulatory body with authority to review your complaint. In addition, mediation is available for disputes greater than $100. Nothing in the Arbitration, Waiver of Jury Trial, and Class Action Waiver Section below is intended to bar your right to make a complaint or request mediation. ARBITRATION. Think’s Arbitration and Class Action Wavier Policy Addendum, which is available and provided to you during the enrollment process is incorporated herein and made a part hereof, contains additional details and a complete description of the terms and conditions of the Arbitration and Class Action Waiver Policy, including your ability to opt out. Warranties. THINK MAKES NO EXPRESS REPRESENTATION OR WARRANTIES WITH REGARD TO THE PROVISION OF ELECTRIC SERVICE AND DISCLAIMS ANY AND ALL WARRANTIES, EXPRESSED OR IMPLIED, OR ARISING OUT OF ANY COURSE OF DEALING OR USAGE OF TRADE EXCEPT WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Limitation of Liability. You will be deemed to be in exclusive control (and responsible for any damages or injury caused thereby) of the electric power after receipt at the delivery point(s). TO THE FULLEST EXTENT PERMITTED BY LAW, THINK WILL NOT BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, PUNITIVE, EXEMPLARY, OR INDIRECT DAMAGES (INCLUDING LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES), WHETHER BY STATUTE, IN CONTRACT OR TORT, EVEN IF THE RESULT OF NEGLIGENCE (WHETHER SOLE, JOINT, CONCURRENT, ACTIVE, OR PASSIVE). ALL OTHER LIABILITY WILL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, AND SUCH DIRECT ACTUAL DAMAGES WILL BE THE SOLE AND EXCLUSIVE REMEDY. YOU HEREBY WAIVE ALL OTHER REMEDIES AT LAW OR IN EQUITY. THERE ARE NO THIRD-PARTY BENEFICIARIES TO THIS AGREEMENT. To the extent any damages required to be paid hereunder are liquidated, the Parties acknowledge that the damages are not intended and shall not be construed as a penalty, such damages are difficult or impossible to determine, that otherwise obtaining an adequate remedy is inconvenient or impossible, and that the liquidated damages constitute a reasonable approximation of the harm or loss.

  • Administrative Claims Requirements and Procedures No suit or arbitration shall be brought arising out of this Agreement against City unless a claim has first been presented in writing and filed with City and acted upon by City in accordance with the procedures set forth in Chapter 1.34 of the Chula Vista Municipal Code, as same may be amended, the provisions of which, including such policies and procedures used by City in the implementation of same, are incorporated herein by this reference. Upon request by City, Consultant shall meet and confer in good faith with City for the purpose of resolving any dispute over the terms of this Agreement.

  • Notice and Procedures If any suit, action, proceeding (including any governmental or regulatory investigation), claim or demand shall be brought or asserted against any person in respect of which indemnification may be sought pursuant to either paragraph (a) or (b) above, such person (the “Indemnified Person”) shall promptly notify the person against whom such indemnification may be sought (the “Indemnifying Person”) in writing; provided that the failure to notify the Indemnifying Person shall not relieve it from any liability that it may have under paragraph (a) or (b) above except to the extent that it has been materially prejudiced (through the forfeiture of substantive rights or defenses) by such failure; and provided, further, that the failure to notify the Indemnifying Person shall not relieve it from any liability that it may have to an Indemnified Person otherwise than under paragraph (a) or (b) above. If any such proceeding shall be brought or asserted against an Indemnified Person and it shall have notified the Indemnifying Person thereof, the Indemnifying Person shall retain counsel reasonably satisfactory to the Indemnified Person (who shall not, without the consent of the Indemnified Person, be counsel to the Indemnifying Person) to represent the Indemnified Person in such proceeding and shall pay the fees and expenses of such counsel related to such proceeding, as incurred. In any such proceeding, any Indemnified Person shall have the right to retain its own counsel, but the fees and expenses of such counsel shall be at the expense of such Indemnified Person unless (i) the Indemnifying Person and the Indemnified Person shall have mutually agreed to the contrary; (ii) the Indemnifying Person has failed within a reasonable time to retain counsel reasonably satisfactory to the Indemnified Person; (iii) the Indemnified Person shall have reasonably concluded that there may be legal defenses available to it that are different from or in addition to those available to the Indemnifying Person; or (iv) the named parties in any such proceeding (including any impleaded parties) include both the Indemnifying Person and the Indemnified Person and representation of both parties by the same counsel would be inappropriate due to actual or potential differing interest between them. It is understood and agreed that the Indemnifying Person shall not, in connection with any proceeding or related proceedings in the same jurisdiction, be liable for the fees and expenses of more than one separate firm (in addition to any local counsel) for all Indemnified Persons, and that all such fees and expenses shall be paid or reimbursed as they are incurred. Any such separate firm for any Underwriter, its affiliates, directors and officers and any control persons of such Underwriter shall be designated in writing by the Representatives and any such separate firm for the Company, its directors, its officers who signed the Registration Statement and any control persons of the Company shall be designated in writing by the Company. The Indemnifying Person shall not be liable for any settlement of any proceeding effected without its written consent, but if settled with such consent or if there be a final judgment for the plaintiff, the Indemnifying Person agrees to indemnify each Indemnified Person from and against any loss or liability by reason of such settlement or judgment. Notwithstanding the foregoing sentence, if at any time an Indemnified Person shall have requested that an Indemnifying Person reimburse the Indemnified Person for fees and expenses of counsel as contemplated by this paragraph, the Indemnifying Person shall be liable for any settlement of any proceeding effected without its written consent if (i) such settlement is entered into more than 30 days after receipt by the Indemnifying Person of such request and (ii) the Indemnifying Person shall not have reimbursed the Indemnified Person in accordance with such request prior to the date of such settlement. No Indemnifying Person shall, without the written consent of the Indemnified Person, effect any settlement of any pending or threatened proceeding in respect of which any Indemnified Person is or could have been a party and indemnification could have been sought hereunder by such Indemnified Person, unless such settlement (x) includes an unconditional release of such Indemnified Person, in form and substance reasonably satisfactory to such Indemnified Person, from all liability on claims that are the subject matter of such proceeding and (y) does not include any statement as to or any admission of fault, culpability or a failure to act by or on behalf of any Indemnified Person.

  • Claims and Review Procedure In the event that any claim for benefits that must initially be submitted in writing to the Board of Directors, is denied (in whole or in part) hereunder, the claimant shall receive from First Charter a notice of denial in writing within 60 days, written in a manner calculated to be understood by the claimant, setting forth the specific reasons for denial, with specific reference to pertinent provisions of this Supplemental Agreement. Any disagreements about such interpretations and construction shall be submitted to an arbitrator subject to the rules and procedures established by the American Arbitration Association. The arbitrator shall be acceptable to both First Charter and the Executive (or Beneficiary); if the parties cannot agree on a single arbitrator, the disagreement shall be heard by a panel of three arbitrators, with each party to appoint one arbitrator and the third to be chosen by the other two. No member of the Board of Directors shall be liable to any person for any action taken under Article VIII except those actions undertaken with lack of good faith.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!