MULTIPLE TENANT OR OCCUPANT(S) Each individual that is considered
NUMBER OF OCCUPANTS Tenant agrees that the House shall be occupied by no more than [Total Number of Occupants] persons, including no more than [Maximum Number of Children] under the age of eighteen (18) years, without the prior written consent of Landlord.
Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).
Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time:
(a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways;
(b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available;
(c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas;
(d) To add additional buildings and improvements to the Common Areas;
(e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and
(f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.
OCCUPANTS The Premises is to be occupied strictly as a residential dwelling with the following individual(s) in addition to the Tenant: (check one)
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Damage or Destruction If any Property shall be damaged or destroyed, in whole or in part, by fire or other property hazard or casualty, Borrower shall give prompt notice thereof to Lender and one hundred (100%) percent of the net amount of all insurance proceeds received by Lender or Borrower as a result of such damage or destruction after deduction of reasonable costs and the expenses, if any, in collecting the same, shall be applied in reduction of the outstanding Principal Balance under the Note pertaining to the Damaged Property. Notwithstanding anything to the contrary set forth above, if a particular Property (a "DAMAGED PROPERTY") shall be damaged or destroyed, in whole or in part, by fire or other casualty, Lender shall, in accordance with the provisions of this Section hereinafter set forth, make the net amount of all insurance proceeds received by Lender pursuant to the provisions of this Agreement as a result of such damage or destruction after deduction of its reasonable costs and expenses, if any, in collecting the same (hereinafter referred to as the "NET PROCEEDS") available for the repair and restoration of the Damaged Property, provided that (i) no default shall have occurred and shall be continuing under the Loan Documents, (ii) Borrower shall commence the repair and restoration of the Damaged Property, as nearly as possible to the condition the Damaged Property was in immediately prior to such fire or other casualty, with such alterations as may be approved by Lender, as soon as reasonably practicable, and shall diligently pursue the same to satisfactory completion, (iii) Lender shall be satisfied that any operating deficits which will be incurred with respect to the Damaged Property as a result of the occurrence of any such fire or other casualty will be covered out of the Net Proceeds or by Borrower out-of-pocket or with the proceeds, if any, of business interruption or rental interruption insurance, (iv) Lender shall be satisfied that, within a reasonable period of time, not to exceed one hundred eighty (180) days following the completion of such repair and restoration of the Damaged Property, the gross cash flow and the net cash flow of the Damaged Property will be restored to a level sufficient to cover all carrying costs and operating expenses of the Damaged Property, (v) Lender shall be satisfied that the repair and restoration of the Damaged Property will be completed on or before the earlier to occur of (w) ninety (90) days prior to the Maturity Date, or (x) the date on which the business interruption insurance covered by such Borrower shall expire, (vi) Lender shall be satisfied that all of the terms, covenants and provisions of this Agreement and the other Loan Documents will continue to be complied with during and subsequent to the completion of such repair and restoration and (vii) Borrower and ARC IV shall execute and deliver to Lender a completion guaranty in form and substance satisfactory to Lender pursuant to the provisions of which Borrower and ARC IV shall jointly and severally guaranty to Lender the lien-free completion of the repair and restoration of the Damaged Property in accordance with the provisions of this paragraph. The Net Proceeds shall be held by Lender in an interest-bearing account, and until disbursed in accordance with the provisions of this paragraph, shall constitute additional security for the payment of the Debt. The Net Proceeds together with interest earned thereon, shall be disbursed by Lender to, or as directed by, Borrower from time to time during the course of the repair and restoration of the Damaged Property, upon receipt of evidence satisfactory to Lender (which evidence shall in each instance and to the full extent required by Lender include receipted bills, invoices, lien waivers and a continuation and date down of title to the Damaged Property in form satisfactory to Lender and issued by the title company insuring the lien of the Mortgage encumbering such Property or another title company satisfactory to Lender) that (i) all materials installed and work and labor performed (except to the extent that they are to be paid for out of the requested disbursement) in connection with the repair and restoration of the Damaged Property have been paid for in full, and (ii) there exist no notice of pendency, stop order, notice of intention to file mechanic's or materialman's lien, mechanic's or materialman's lien or other lien or encumbrance of any nature whatsoever on the Damaged Property arising out of the repair and restoration of the Damaged Property which have not either been fully bonded to the satisfaction of Lender and discharged of record or in the alternative fully insured over to the satisfaction of Lender by the title company insuring the lien of the Mortgage encumbering the Damaged Property. The repair and restoration of the Damaged Property shall be done and completed by Borrower in an expeditious and diligent fashion and in compliance with all applicable governmental laws, rules and regulations (including, without limitation, all applicable Environmental Requirements), and all plans and specifications required in connection with the repair and restoration of the Damaged Property shall be subject to review and acceptance in all respects by Lender and by the Consultant. If Lender fails to respond within ten (10) Business Days following a request and submissions of plans and specifications for approval, such plans and specification shall be deemed approved by Lender. Upon the occurrence of an Event of Default, Lender shall have the use of such plan and specifications and all permits, licenses and approvals required or obtained in connection with the repair and restoration of the Damaged Property. The identity of the contractors, subcontractors and materialmen engaged in the repair and restoration of the Damaged Property, as well as the contracts under which they have been engaged, shall be identified to Lender and Consultant, if any. All costs and expenses incurred by Lender in connection with making the Net Proceeds available for the repair and restoration of the Damaged Property including, without limitation, reasonable counsel fees and reasonable fees of the Consultant, shall be paid by Borrower. In no event shall Lender be obligated to make disbursements of the Net Proceeds in excess of an amount equal to the costs actually incurred from time to time for work in place as part of the repair and restoration of the Damaged Property,
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
