Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representati...
Tenant Delays means any delay in the completion of the Tenant Improvements resulting from any or all of the following: (a) Tenant's failure to timely perform any of its obligations pursuant to this Work Letter Agreement, including any failure to complete, on or before the due date therefor, any action item which is Tenant's responsibility pursuant to the Work Schedule delivered by Landlord to Tenant pursuant to this Work Letter Agreement; (b) Tenant's changes to Space Plans or Final Plans after Landlord's approval thereof; (c) Tenant's request for materials, finishes, or installations which are not readily available or which are incompatible with the Standards; (d) any delay of Tenant in making payment to Landlord for Tenant's share of the Work Cost; or (e) any other act or failure to act by Tenant, Tenant's employees, agents, architects, independent contractors, consultants and/or any other person performing or required to perform services on behalf of Tenant.
Tenant Delays means any delays caused or contributed to by Tenant.
Examples of Tenant Delays in a sentence
The “Commencement Date” shall be the earliest of: (i) the date Landlord Delivers the Premises to Tenant; (ii) the date Landlord could have Delivered the Premises but for Tenant Delays; and (iii) the date Tenant conducts any business in the Premises or any part thereof.
However, if Landlord is delayed in the performance of the Landlord Work as a result of any Tenant Delay(s) (defined below), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.
Landlord’s Work shall be deemed substantially completed as of the date when Landlord’s Work would have been substantially completed but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment.
It is the intention of the parties that all of such delays will be considered Tenant Delays for which Tenant shall be wholly and completely responsible for any and all consequences related to such delays, including, without limitation, any costs and expenses attributable to increases in labor or materials.
Landlord shall have no obligation to interrupt or modify the Tenant Improvement Work pending Tenant’s approval of a change order, but if Tenant fails to timely approve a change order, Landlord may (but shall not be required to) suspend the applicable Tenant Improvement Work, in which event any related critical path delays because of such suspension shall constitute Tenant Delays hereunder.
More Definitions of Tenant Delays
Tenant Delays means any delay in the completion of the Tenant Improvements resulting from any or all of the following: (a) Tenant’s failure to timely perform any of its obligations pursuant to this Work Letter, including any failure to complete, on or before the due date therefor, any action item which is Tenant’s responsibility pursuant to the Work Schedule or any schedule delivered by Landlord to Tenant pursuant to this Work Letter, (b) Tenant’s changes to the Plans; (c) Tenant’s request for materials, finishes, or installations which are not readily available or which are incompatible with the Standards; (d) any delay of Tenant in making payment to Landlord for Tenant’s share of any costs in excess of the cost of the Tenant Improvements as described in the Plans; or (e) any other act or failure to act by Tenant, Tenant’s employees, agents, architects, independent contractors, consultants and/or any other person performing or required to perform services on behalf of Tenant.
Tenant Delays means any delay in the completion of the Improvements resulting from any or all of the following: (1) Tenant's failure to timely perform any of its obligations pursuant to this Work Letter, including Tenant's failure to process timely the building permit for the Tenant Improvements and any failure to complete, on or before the due date therefor, any action item which is Tenant's responsibility pursuant to this Work Letter, including Tenant's failure to grant approvals and/or make payments within the time frames described herein; (2) Tenant's requested modifications to the Preliminary Plans, the Final Plans or any Tenant-initiated Change Orders; (3) Tenant's request for materials, finishes, or installations which are not readily available, (4) any delay in any way whatsoever arising from Tenant's right to conduct "Inspections" under Section 14 below, (5) Change Order Delays, (6) any delay due to Tenant's failure to timely approve fee plans and specifications and/or the budget related to the Tenant Improvements, or (7) any other act or failure to act by Tenant, Tenant's Representative, Tenant's Architect, Tenant's employees, agents, independent contractors, consultants and/or any other person performing or required to perform services on behalf of Tenant. "Force Majeure Delays" as used herein means delays resulting from causes beyond the reasonable control of Landlord or the Contractor, including, without limitation, any delay caused by any action, inaction, order, ruling, moratorium, regulation, statute, condition or other decision of any private party or governmental agency having jurisdiction over any portion of the project, over the construction of the Improvements or over any uses thereof, or by delays in inspections or in issuing approvals by private parties or permits by governmental agencies, or by fire, flood, inclement weather, strikes, lockouts or other labor or industrial disturbance (whether or not on the part of agents or employees of either party hereto engaged in the construction of the Improvements), civil disturbance, order of any government, court or regulatory body claiming jurisdiction or otherwise, act of public enemy, war, riot, sabotage, blockage, embargo, failure or inability to secure materials, supplies or labor through ordinary sources by reason of shortages or priority, discovery of hazardous or toxic materials, earthquake, or other natural disaster, delays caused by any dispute resolution process, or any cause whatsoever beyond ...
Tenant Delays means any delay in the completion of the Landlord’s Work resulting from any or all of the following:
Tenant Delays means any and all delays due to the fault of the Tenant, including without limitation Tenant's failure to deliver to Landlord prior to the Commencement Date executed copies of policies of insurance or certificates thereof as required under Section 11.8.
Tenant Delays means delays caused by Tenant, its employees, agents or contractors which begin one (1) business day following notice thereof from Landlord to Tenant. Furthermore, if Landlord shall not have substantially completed Landlord’s Work with respect to restroom renovation with respect to the Initial Premises by September 14, 2014, then Tenant shall be entitled to a credit, for each day from September 1, 2014 to the date of such substantial completion, against Base Rent equal to one (1) day of Base Rent applicable to any floor of Tower IV (based on rentable square feet on that floor) with respect to which the Landlord’s Work thereon shall not have been substantially completed. In addition, if Tenant adds space to the Initial Premises and as a result of such addition, Tenant is leasing more than 50% of a floor of a Tower, Landlord shall renovate the restrooms on such floor as contemplated by Exhibit B-2, and if Landlord shall not have substantially completed such restroom renovation on such floor by the date which is one hundred twenty (120) days following the date on which the Landlord delivers the space to Tenant that results in Tenant being the tenant of more than 50% of such floor, then Tenant shall be entitled to a credit, for each day following the end of such one hundred twenty (120) day period to the date of such substantial completion, against Base Rent due under this Lease equal to one (1) day of Base Rent applicable to the additional space on such floor which resulted in Landlord’s obligation.
Tenant Delays means any or all of the following:
Tenant Delays means delays in the design, construction or Substantial Completion of the Improvements by or on behalf of Landlord to the extent caused or contributed by Tenant or its agents, employees, representatives, contractors, subcontractors, consultants or invitees.