Changes to Critical Path Sample Clauses

Changes to Critical Path. (a) Any changes to the critical path of the Construction Schedule initiated by Project Co which affect the Phased Occupancy Dates, the Scheduled Substantial Completion Date or the Scheduled Final Completion Date must be approved in writing by Owner. Subject to the terms of Schedule 11 – Change Procedure, any Owner approval of such changes to the critical path does not entitle Project Co to a Change Order, an extension of the Contract Time or an addition to the Guaranteed Price.
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Changes to Critical Path. (a) Any changes to the critical path of the Works Schedule initiated by Project Co which affect the Scheduled Substantial Completion Date or the Scheduled Final Completion Date must be approved in writing by the College. Subject to the terms of Schedule 22 – Variation Procedure, any College approval of such changes to the critical path does not entitle Project Co to a Variation, an extension of time or an addition to the Guaranteed Price.
Sample 1Sample 2Sample 3See All (5)
Changes to Critical Path. (a) Any changes to the critical path of the Works Schedule initiated by Project Co which affect the Scheduled Substantial Completion Date or the Scheduled Final Completion Date must be approved in writing by HMQ. Subject to the terms of Schedule 22 – Variation Procedure, any HMQ approval of such changes to the critical path does not entitle Project Co to a Variation, an extension of the Contract Time or an addition to the Guaranteed Price.
Sample 1
Changes to Critical Path. (a) Any changes to the critical path of the Works Schedule initiated by Project Co which affect the Scheduled Substantial Completion Date, the Scheduled PGW Substantial Completion Date, the Scheduled Final Completion Date or the Scheduled PGW Final Completion Date must be approved in writing by HMQ. Subject to the terms of Schedule 22 – Variation Procedure, any HMQ approval of such changes to the critical path does not entitle Project Co to a Variation, an extension of time or an addition to the Guaranteed Price.
Sample 1
Changes to Critical Path. (a) Any change to the critical path of the Works Schedule initiated by Project Co which affects a Scheduled Phase Completion Date, the Scheduled Tower Interim Completion Date, the Scheduled Substantial Completion Date or the Scheduled Final Completion Date must be approved in writing by JBH. Subject to the terms of Schedule 22 – Variation Procedure, any JBH approval of such changes to the critical path does not entitle Project Co to a Variation, an extension of time or an addition to the Guaranteed Price.
Sample 1

Related to Changes to Critical Path

  • Changes to Scope of Work The City of Nashua may, at any time, by written order, make changes to the general scope, character, or cost of this contract and in the services or work to be performed, either increasing or decreasing the scope, character, or cost of Independent Contractor's performance under the contract. Independent Contractor shall provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. If the change causes an increase or a decrease in Independent Contractor's cost or time required for performance of the contract as a whole, an equitable adjustment shall be made and the contract accordingly modified in writing. Any claim of Independent Contractor for adjustment under this clause shall be asserted in writing within 30 days of the date the City of Nashua notified Independent Contractor of the change. When Independent Contractor seeks changes, Independent Contractor shall, before any work commences, estimate their effect on the cost of the contract and on its schedule and notify the City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. Except as provided in this paragraph, Independent Contractor shall implement no change unless the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the provisions of this contract shall apply to all changes. The City of Nashua may provide verbal approval of a change when the City of Nashua, in its sole discretion, determines that time is critical or public health and safety are of concern. Any verbal approval shall be confirmed in writing as soon as practicable. Any change undertaken without prior City of Nashua approval shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract termination.

  • Changes to Service We may, from time to time, modify the Service to reflect improvements and other changes and modifications to our network. In addition, we reserve the right to discontinue or limit Service as required to comply with or satisfy our obligations under applicable laws or regulations, including when changes to or interpretations of such laws and regulations have a material, adverse effect on the business, technical or economic feasibility of providing Service, as determined by us in our reasonable judgment.

  • Changes to Services The Parties acknowledge and agree that there will be changes to the scope of the Services during the Contract Period. The Customer may amend the Stories that are comprised within the Minimum Marketable Features of a Release at any time during the Release at no additional charge and without adopting the Change Control Procedure set out in Clause 28 above provided that: the Customer shall not be entitled to make any changes to the Stories that form the subject of a Sprint following the mutual agreement by the Parties of the Sprint Plan for that Sprint; new Stories and/or changes to existing Stories may only be introduced if: existing Stories with an equivalent number of Story Points are removed; or existing Stories are reduced in size by the equivalent number of Story Points, such that the total number of Story Points for the Release remains constant throughout the Release. The Supplier shall consider any request by the Customer to increase the number of Story Points for a Release, and may, subject to the Change Control Procedure set out at Clause 28, agree to such request.

  • Changes to the Website We may update the content on this Website from time to time, but its content is not necessarily complete or up-to-date. Any of the material on the Website may be out of date at any given time, and we are under no obligation to update such material.

  • NOTIFICATION OF CHANGES TO AGENTS Following receipt of notice of resignation from an Agent and immediately after appointing a successor or new Agent or on giving notice to terminate the appointment of any Agent, the Principal Paying Agent (on behalf of and at the expense of the Issuer) shall give or cause to be given not more than 45 days' nor less than 30 days' notice of the fact to the Noteholders in accordance with the Conditions.

  • Changes to the Work 7.1 Changes to the Work may be accomplished by preparation of and execution of a change order or construction change directive. Change orders or construction change directives will be preceded by a change proposal request initiated by the Architect. The Construction Manager shall provide prices and details within 30 days of receipt of a change proposal request, and the Architect shall forward the completed change proposal request to the Owner within 15 days after receipt of the information provided by the Construction Manager.

  • Changes to Agreement We reserve the right to change any of the terms of this Agreement or any Specifications or Guidelines governing the Service at any time in our sole discretion. All changes will be effective upon posting to the Service. However, for all changes to this Agreement, excluding Specifications and Guidelines, we will post a notice of change for thirty (30) days. You are responsible for reviewing the notice and any applicable changes. YOUR CONTINUED USE OF THIS SERVICE FOLLOWING OUR POSTING OF ANY CHANGES WILL CONSTITUTE YOUR ACCEPTANCE OF SUCH CHANGES. 11) Prime Publishing Intellectual Property. Without our prior written consent, you may not use our intellectual property, including, without limitation, our trademarks, trade names, trade dress, or copyrighted material, in any manner. 12) Communications. Prime Publishing and its Affiliates may communicate with you in connection with the Service, electronically and in other Media, and you consent to such communications regardless of any "Customer Communication Preferences" (or similar preferences or requests) you may have indicated on the web sites of Prime Publishing or its Affiliates or by any other means. 13) Waiver. PRIME PUBLISHING AND ITS AFFILIATES WILL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, OR CONSEQUENTIAL DAMAGES (INCLUDING BUT NOT LIMITED TO SUCH DAMAGES ARISING FROM BREACH OF CONTRACT OR WARRANTY OR FROM NEGLIGENCE OR STRICT LIABILITY) ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT, EVEN IF WE HAVE BEEN ADVISED OF (OR KNEW OR SHOULD KNOWN OF) THE POSSIBILITY OF SUCH DAMAGES. 14) Disclaimer. PRIME PUBLISHING PROVIDES THE SERVICE "AS IS" WITHOUT WARRANTY OF ANY KIND. 15)

  • Post-Commercial Operation Date Testing and Modifications Each Party shall at its own expense perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Large Generating Facility with the Participating TO’s Transmission System in a safe and reliable manner. Each Party shall have the right, upon advance written notice, to require reasonable additional testing of the other Party’s facilities, at the requesting Party’s expense, as may be in accordance with Good Utility Practice.

  • Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.

  • Changes to the Service We reserve the right to terminate, modify, add and remove features from the Service at any time in our sole discretion. You may reject changes by discontinuing use of the Service. Your continued use of the Service will constitute your acceptance of and agreement to such changes. Maintenance to the Service may be performed from time-to-time resulting in interrupted service, delays or errors in the Service and we shall have no liability for any such interruptions, delays or errors.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!