Classification Society instructions and undertaking Sample Clauses

Classification Society instructions and undertaking. Each Borrower shall instruct the Classification Society referred to in Clause 14.3(b) and procure that the Classification Society undertakes with the Security Trustee: (a) to send to the Security Trustee, following receipt of a written request from the Security Trustee, certified true copies of all original class records held by the Classification Society in relation to that Borrower’s Ship; (b) to allow the Security Trustee (or its agents), at any time and from time to time, to inspect the original class and related records of that Borrower and the Ship owned by it either (i) electronically (through the Classification Society directly or by way of indirect access via the Borrowers’ account manager and designating the Security Trustee as a user or administrator of the system under its account) or (ii) in person at the offices of the Classification Society, and to take copies of them electronically or otherwise; (c) to notify the Security Trustee immediately by Email to nxxx.xxxxxxxxxx@xxxxxxx.xxx and txxxxxx@xxxxxxx.xxx if the Classification Society: (i) receives notification from that Borrower or any other person that such Ship’s Classification Society is to be changed; (ii) imposes a condition of class or issues a class recommendation in respect of that Ship; or (iii) becomes aware of any facts or matters which may result in or have resulted in a change, suspension, discontinuance, withdrawal or expiry of that Ship’s class under the rules or terms and conditions of that Borrower’s or that Ship’s membership of the Classification Society; (d) following receipt of a written request from the Security Trustee: (i) to confirm that such Borrower is not in default of any of its contractual obligations or liabilities to the Classification Society and, without limiting the foregoing, that it has paid in full all fees or other charges due and payable to the Classification Society; or (ii) if that Borrower is in default of any of its contractual obligations or liabilities to the Classification Society, to specify to the Security Trustee in reasonable detail the facts and circumstances of such default, the consequences of such default, and any remedy period agreed or allowed by the Classification Society.
Sample 1Sample 2Sample 3See All (15)
AutoNDA by SimpleDocs
Classification Society instructions and undertaking. Each Borrower shall instruct the Classification Society referred to in Clause 14.3(b) and procure that the Classification Society undertakes with the Security Trustee:
Sample 1
Classification Society instructions and undertaking. The Borrower shall instruct the Classification Society through a letter sent by the Borrower to the Classification Society in the form attached hereto as Exhibit H-1 (and procure that the Classification Society undertakes with the Security Trustee through a letter in the form attached hereto as Exhibit H-2):
Sample 1
Classification Society instructions and undertaking. Each Shipowner shall instruct the Classification Society referred to in Section 2(b) above (and procure that the Classification Society undertakes with the Common Security Agent or relevant Existing Security Agent, as applicable,):
Sample 1

Related to Classification Society instructions and undertaking

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:

  • Representations Relating to Documents and Legal Compliance Borrower represents and warrants to Silicon as follows: All statements made and all unpaid balances appearing in all invoices, instruments and other documents evidencing the Receivables are and shall be true and correct and all such invoices, instruments and other documents and all of Borrower's books and records are and shall be genuine and in all respects what they purport to be, and all signatories and endorsers have the capacity to contract. All sales and other transactions underlying or giving rise to each Receivable shall fully comply with all applicable laws and governmental rules and regulations. All signatures and endorsements on all documents, instruments, and agreements relating to all Receivables are and shall be genuine, and all such documents, instruments and agreements are and shall be legally enforceable in accordance with their terms.

  • Evidence of Compliance with Conditions Precedent The Guarantor shall provide to the Guarantee Trustee such evidence of compliance with such conditions precedent, if any, provided for in this Guarantee Agreement that relate to any of the matters set forth in Section 314(c) of the Trust Indenture Act. Any certificate or opinion required to be given by an officer pursuant to Section 314(c)(1) may be given in the form of an Officers' Certificate.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • General Conditions Costs Contractor is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from Owner through Substantial Completion of the Project, plus 30 calendar days. Contractor is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion, plus 30 calendar days, must be approved in advance by Owner. Allowable General Conditions items are identified below and in Exhibit “D” attached to this Agreement. These items shall be included in the General Conditions Cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the Schedule of Values. Items not specifically included below or in Exhibit “D” will not be allowed as General Condition Costs.

  • Data Protection Impact Assessment and Prior Consultation Processor shall provide reasonable assistance to the Company with any data protection impact assessments, and prior consultations with Supervising Authorities or other competent data privacy authorities, which Company reasonably considers to be required by article 35 or 36 of the GDPR or equivalent provisions of any other Data Protection Law, in each case solely in relation to Processing of Company Personal Data by, and taking into account the nature of the Processing and information available to, the Contracted Processors.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • Resolution of Conflicts of Interest; Standards of Conduct and Modification of Duties (a) Unless otherwise expressly provided in this Agreement or any Group Member Agreement, whenever a potential conflict of interest exists or arises between the General Partner or any of its Affiliates, on the one hand, and the Partnership, any Group Member or any Partner, on the other, any resolution or course of action by the General Partner or its Affiliates in respect of such conflict of interest shall be permitted and deemed approved by all Partners, and shall not constitute a breach of this Agreement, of any Group Member Agreement, of any agreement contemplated herein or therein, or of any duty stated or implied by law or equity, if the resolution or course of action in respect of such conflict of interest is (i) approved by Special Approval, (ii) approved by the vote of a majority of the Common Units (excluding Common Units owned by the General Partner and its Affiliates), (iii) on terms no less favorable to the Partnership than those generally being provided to or available from unrelated third parties or (iv) fair and reasonable to the Partnership, taking into account the totality of the relationships between the parties involved (including other transactions that may be particularly favorable or advantageous to the Partnership). The General Partner shall be authorized but not required in connection with its resolution of such conflict of interest to seek Special Approval of such resolution, and the General Partner may also adopt a resolution or course of action that has not received Special Approval. If Special Approval is not sought and the Board of Directors of the General Partner determines that the resolution or course of action taken with respect to a conflict of interest satisfies either of the standards set forth in clauses (iii) or (iv) above, then it shall be presumed that, in making its decision, the Board of Directors of the General Partner acted in good faith, and in any proceeding brought by any Limited Partner or by or on behalf of such Limited Partner or any other Limited Partner or the Partnership challenging such approval, the Person bringing or prosecuting such proceeding shall have the burden of overcoming such presumption. Notwithstanding anything to the contrary in this Agreement or any duty otherwise existing at law or equity, the existence of the conflicts of interest described in the Registration Statement are hereby approved by all Partners and shall not constitute a breach of this Agreement. (b) Whenever the General Partner makes a determination or takes or declines to take any other action, or any of its Affiliates causes it to do so, in its capacity as the general partner of the Partnership as opposed to in its individual capacity, whether under this Agreement, any Group Member Agreement or any other agreement contemplated hereby or otherwise, then, unless another express standard is provided for in this Agreement, the General Partner, or such Affiliates causing it to do so, shall make such determination or take or decline to take such other action in good faith and shall not be subject to any other or different standards imposed by this Agreement, any Group Member Agreement, any other agreement contemplated hereby or under the Delaware Act or any other law, rule or regulation or at equity. In order for a determination or other action to be in “good faith” for purposes of this Agreement, the Person or Persons making such determination or taking or declining to take such other action must believe that the determination or other action is in the best interests of the Partnership, unless the context otherwise requires. (c) Whenever the General Partner makes a determination or takes or declines to take any other action, or any of its Affiliates causes it to do so, in its individual capacity as opposed to in its capacity as the general partner of the Partnership, whether under this Agreement, any Group Member Agreement or any other agreement contemplated hereby or otherwise, then the General Partner, or such Affiliates causing it to do so, are entitled to make such determination or to take or decline to take such other action free of any fiduciary duty or obligation whatsoever to the Partnership, any Limited Partner, and the General Partner, or such Affiliates causing it to do so, shall not be required to act in good faith or pursuant to any other standard imposed by this Agreement, any Group Member Agreement, any other agreement contemplated hereby or under the Delaware Act or any other law, rule or regulation or at equity. By way of illustration and not of limitation, whenever the phrase, “at the option of the General Partner,” or some variation of that phrase, is used in this Agreement, it indicates that the General Partner is acting in its individual capacity. For the avoidance of doubt, whenever the General Partner votes or transfers its Partnership Interests, or refrains from voting or transferring its Partnership Interests, it shall be acting in its individual capacity. (d) Notwithstanding anything to the contrary in this Agreement, the General Partner and its Affiliates shall have no duty or obligation, express or implied, to (i) sell or otherwise dispose of any asset of the Partnership Group other than in the ordinary course of business or (ii) permit any Group Member to use any facilities or assets of the General Partner and its Affiliates, except as may be provided in contracts entered into from time to time specifically dealing with such use. Any determination by the General Partner or any of its Affiliates to enter into such contracts shall be at its option. (e) Except as expressly set forth in this Agreement, neither the General Partner nor any other Indemnitee shall have any duties or liabilities, including fiduciary duties, to the Partnership or any Limited Partner and the provisions of this Agreement, to the extent that they restrict, eliminate or otherwise modify the duties and liabilities, including fiduciary duties, of the General Partner or any other Indemnitee otherwise existing at law or in equity, are agreed by the Partners to replace such other duties and liabilities of the General Partner or such other Indemnitee. (f) The Unitholders hereby authorize the General Partner, on behalf of the Partnership as a partner or member of a Group Member, to approve of actions by the general partner or managing member of such Group Member similar to those actions permitted to be taken by the General Partner pursuant to this Section 7.9.

  • Conditions Precedent to Obligation of Purchaser The obligation of Purchaser to consummate the transaction hereunder shall be subject to the fulfillment on or before the Closing Date of all of the following conditions, any or all of which may be waived by Purchaser in its sole discretion: (a) Seller shall have delivered to Purchaser all of the items required to be delivered to Purchaser pursuant to the terms of this Agreement, including but not limited to the tenant estoppel certificates required under Section 7.2 and the documents and other items provided for in Section 10.3. (b) All of the representations and warranties of Seller contained in this Agreement shall be true and correct in all material respects as of the Closing Date (with appropriate modifications permitted under this Agreement). For the avoidance of doubt, the representations and warranties contained in Subsections 8.1 (f) and (g) may be modified at Closing to reflect changes in the identity of the Tenants and the Leases (that are not in violation of the operating covenants set forth in Section 7.1 above), notices received from any Tenant that it is terminating its Lease, vacating its premises, or filing for bankruptcy, any Tenant defaults between the date hereof and Closing, and any changes in the Service Contracts (in accordance with the operating covenants set forth in Section 7.1 above), and any defaults by the service providers thereunder. (c) Seller shall have performed and observed, in all material respects, all covenants and agreements of this Agreement to be performed and observed by Seller as of the Closing Date. (d) At or prior to Closing, the Title Company shall be prepared, or First American Title Insurance Company’s National Office shall be prepared if the Title Company is not so prepared, to irrevocably commit to issue to Purchaser a standard Pennsylvania basic owner’s title insurance policy (without regard to any endorsements required by Purchaser or its lender) in the amount of the Purchase Price with respect to the Property pursuant to a marked-up title commitment or a pro-forma policy effective as of the Closing Date, subject only to Permitted Exceptions and the standard printed exceptions on such policy, upon the fulfillment by Seller and Purchaser of the Schedule B, Section I requirements, and the payment by Purchaser of the requisite premium. Seller shall have the right to arrange for First American Title Insurance Company’s National Office to become involved in such title decisions. (e) Closing shall simultaneously take place between KPG Purchasers and M-C Sellers under all of the Other P&S Agreements, unless such failure to close thereunder is due to the bad faith and intentional acts of Purchaser or any KPG Purchaser intended to impede Closing or a breach of any material covenant of Purchaser under this Agreement or any KPG Purchaser under the other P&S Agreements of which it is a party. If the conditions precedent to Closing under this Section 9.1 are not satisfied or waived by Purchaser on or before Closing, Purchaser shall have the right to terminate this Agreement and receive a refund of the Xxxxxxx Money Deposit and interest earned thereon and except with respect to the Termination Surviving Obligations, this Agreement shall be null and void and the parties shall have no further obligations to each other hereunder.

  • Inspection of Agreement A copy of this Agreement shall be available at all reasonable times at the principal corporate trust office of the Warrant Agent for inspection by the holder of any Warrant Certificate. The Warrant Agent may require such holder to submit his Warrant Certificate for inspection by it.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!