Common use of CLAUSES INCORPORATED BY REFERENCE Clause in Contracts

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.html. The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN 1997 x x x 52.211-8 ALTERNATE I APR 1984 x x x 52.211-8 ALTERNATE II APR 1984 x x x 52.211-8 ALTERNATE III APR 1984 x x x 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x 52.211-9 ALTERNATE I APR 1984 x x x 52.211-9 ALTERNATE II APR 1984 x x x 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x 52.242-15 STOP-WORK ORDER AUG 1989 x x 52.242-15 ALTERNATE I APR 1984 x 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x 52.247-34 F.O.B. DESTINATION NOV 1991 x 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 x

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.htmlxxxx://xxxxxx.xxx/far/index.html. The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: . CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN 1997 x x x X X X 52.211-8 ALTERNATE I APR 1984 x x x X X X 52.211-8 ALTERNATE II APR 1984 x x x X X X 52.211-8 ALTERNATE III APR 1984 x x x X X X 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x X X X 52.211-9 ALTERNATE I APR 1984 x x x X X X 52.211-9 ALTERNATE II APR 1984 x x x X X X 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x X X X 52.242-15 STOP-WORK ORDER AUG 1989 x x X X 52.242-15 ALTERNATE I APR 1984 x X 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x X 52.247-34 F.O.B. DESTINATION NOV 1991 x X 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 xX

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.htmlxxxx://xxxxxx.xxx/far/index.html. The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN 1997 x x x 52.211-8 ALTERNATE I APR 1984 x x x 52.211-8 ALTERNATE II APR 1984 x x x 52.211-8 ALTERNATE III APR 1984 x x x 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x 52.211-9 ALTERNATE I APR 1984 x x x 52.211-9 ALTERNATE II APR 1984 x x x 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x 52.242-15 STOP-WORK ORDER AUG 1989 x x 52.242-15 ALTERNATE I APR 1984 x 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x 52.247-34 F.O.B. DESTINATION NOV 1991 x 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 x

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Task Order level. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.htmlxxxxx://xxx.xxxxxxxxxxx.xxx/far. The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN Jun 1997 x x x X X X 52.211-8 ALTERNATE I APR 1984 x x x X X X 52.211-8 ALTERNATE II APR 1984 x x x X X X 52.211-8 ALTERNATE III APR 1984 x x x X X X 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x X X X 52.211-9 ALTERNATE I APR 1984 x x x X X X 52.211-9 ALTERNATE II APR 1984 x x x X X X 52.211-9 ALTERNATE III APR 1984 x x x X X X 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x X 52.242-15 STOP-WORK ORDER AUG 1989 x x X X 52.242-15 ALTERNATE I APR 1984 x X 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x X 52.247-34 F.O.B. DESTINATION NOV 1991 x X 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 xX

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same sa me force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.htmlxxxx://xxxxxx.xxx/far/index.html . The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN 1997 x x x X X X 52.211-8 ALTERNATE I APR 1984 x x x X X X 52.211-8 ALTERNATE II APR 1984 x x x X X X 52.211-8 ALTERNATE III APR 1984 x x x X X X 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x X X X 52.211-9 ALTERNATE I APR 1984 x x x X X X 52.211-9 ALTERNATE II APR 1984 x x x X X X 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x X X X 52.242-15 STOP-WORK ORDER AUG 1989 x x X X 52.242-15 ALTERNATE I APR 1984 x X 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x X 52.247-34 F.O.B. DESTINATION NOV 1991 x X 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 xX

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.html. address- xxxxx://xxx.xxxxxxxxxxx.xxx/far/ The following clauses apply to the Master Contract and may apply at the Task Order level, as applicable, subject to specific delivery and performance requirements depending upon the contract type of the Task Order, or as set forth specifically referenced in the applicable Task Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.21152.246-2 INSPECTION OF SUPPLIES— FIXED PRICE AUG 1996 X 52.246-2 ALTERNATE I JUL 1985 X 52.246-2 ALTERNATE II JUL 1985 X 52.246-3 INSPECTION OF SUPPLIES— COST REIMBURSEMENT MAY 2001 X 52.246-4 INSPECTION OF SERVICES— FIXED PRICE AUG 1996 X X 52.246-5 INSPECTION OF SERVICES— COST REIMBURSEMENT APR 1984 X 52.246-6 INSPECTION— TIME-AND-MATERIAL AND LABOR-HOUR MAY 2001 X 52.246-7 INSPECTION OF RESEARCH AND DEVELOPMENT— FIXED PRICE AUG 1996 X 52.246-8 TIME INSPECTION OF DELIVERY JUN 1997 x x x 52.211RESEARCH AND DEVELOPMENT— COST REIMBURSEMENT MAY 2001 X 52.246-8 ALTERNATE I APR 1984 x x x 52.211-8 ALTERNATE II APR 1984 x x x 52.211-8 ALTERNATE III APR 1984 x x x 52.211X 52.246-9 DESIRED AND REQUIRED TIME INSPECTION OF DELIVERY JUN 1997 x x x 52.211-9 ALTERNATE I APR 1984 x x x 52.211-9 ALTERNATE II APR 1984 x x x 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x 52.242(SHORT FORM) APR 1984 X X 52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT DEC 2014 X X X 52.246-15 STOP-WORK ORDER AUG 1989 x x 52.242-15 ALTERNATE I CERTIFICATE OF CONFORMANCE APR 1984 x 52.242X X 52.246-17 GOVERNMENT DELAY OF WORK 16 RESPONSIBILITY FOR SUPPLIES APR 1984 x 52.247-34 F.O.B. DESTINATION NOV 1991 x 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 xX (End of Clause)

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.html. The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN 1997 x x x 52.211-8 ALTERNATE I APR 1984 x x x 52.211-8 ALTERNATE II APR 1984 x x x 52.211-8 ALTERNATE III APR 1984 x x x 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x 52.211-9 ALTERNATE I APR 1984 x x x 52.211-9 ALTERNATE II APR 1984 x x x 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x 52.242-15 STOP-WORK ORDER AUG 1989 x x 52.242-15 ALTERNATE I APR 1984 x 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x 52.247-34 F.O.B. DESTINATION NOV 1991 x 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 x

CLAUSES INCORPORATED BY REFERENCE. (FEB 1998) The following clauses shall apply unless otherwise designated at the Order level. This contract incorporates one or more clauses by reference, with the same sa me force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxxx://xxx.xxxxxxxxxxx.xxx/far/index.htmlxxxx://xxxxxx.xxx/far/index.html. The following clauses apply at the Order level, as applicable, subject to specific delivery and performance requirements as set forth in the applicable Order: CLAUSE # CLAUSE TITLE DATE FP COST TM 52.211-8 TIME OF DELIVERY JUN 1997 x x x X X X 52.211-8 ALTERNATE I APR 1984 x x x X X X 52.211-8 ALTERNATE II APR 1984 x x x X X X 52.211-8 ALTERNATE III APR 1984 x x x X X X 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY JUN 1997 x x x X X X 52.211-9 ALTERNATE I APR 1984 x x x X X X 52.211-9 ALTERNATE II APR 1984 x x x X X X 52.211-9 ALTERNATE III APR 1984 x x x 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT SEP 2000 x X X X 52.242-15 STOP-WORK ORDER AUG 1989 x x X X 52.242-15 ALTERNATE I APR 1984 x X 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 x X 52.247-34 F.O.B. DESTINATION NOV 1991 x X 52.247-35 F.O.B. DESTINATION WITH CONSIGNEES PREMISES APR 1984 xX