Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
TERM; POSSESSION The Term of this Lease shall commence on the Commencement Date and shall end on the Expiration Date, unless extended or sooner terminated in accordance with this Lease. If Landlord is delayed in delivering possession of all or any portion of the Premises to Tenant as of the Commencement Date, Tenant will take possession on the date Landlord delivers possession, which date will then become the Commencement Date (and the Expiration Date will be extended so that the length of the Term remains unaffected by such delay). Subject to this Section 4, Landlord shall not be liable for any loss or damage to Tenant resulting from any delay in delivering possession due to the holdover of any existing tenant or other circumstances outside of Landlord’s reasonable control. In the event that the Tenant Improvements are not Substantially Completed within one hundred (100) days following the date that Landlord receives a building permit to commence the Tenant Improvements in the Premises (the “Delivery Date”), subject to Tenant Delay or force majeure (in the event of either, the Delivery Date shall be extended by one (1) day for each one (1) day of Tenant Delay or force majeure), Landlord shall credit Tenant against Minimum Annual Rent due under this Lease an amount equal to the holdover portion of Tenant’s existing rental obligations under Tenant’s existing Lease actually incurred by Tenant following the Delivery Date, which Tenant represents to Landlord is equal to $17,031.13 per month. Notwithstanding anything in this Lease to the contrary, if the Commencement Date has not occurred on or before one hundred ninety (190) days following the date that Landlord receives a building permit for the Tenant Improvements, for any reason other than Tenant Delay or force majeure, then Tenant shall have the right to terminate this Lease by written notice to Landlord, as Tenant’s sole and exclusive remedy with respect to such delay, except as provided above, subject to Tenant giving Landlord thirty (30) days’ advance written notice of its intention to terminate this Lease if Substantial Completion shall not occur within such thirty (30) day period, in which event all amounts prepaid or deposited by Tenant hereunder shall be promptly returned to Tenant.
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on
Peaceful Possession The Authority hereby warrants that:
a) The Project Site has been acquired through the due process of law and belongs to and is vested with the Authority and that the Authority has full powers to hold, dispose of and deal with the same consistent, inter alia, with the provisions of this Agreement.
b) In the event the Developer is obstructed by any Person claiming any right, title or interest in or over the Project Site or any part thereof, or in the event of any enforcement action including any attachment, distrait, appointment of receiver or liquidator being initiated by any Person claiming to have any interest in/charge or the Project Site or any part thereof, the Authority shall, if called upon by the Developer, defend such claims and proceedings and also keep the Developer indemnified against any consequential loss or damages which the Developer may suffer, on account of any such right, title, interest or charge.
Possession and Control The Grantor has exclusive possession and control of its Equipment and Inventory.
Title to Properties; Possession Under Leases (a) Each of the Borrower and the Subsidiaries has valid title in fee simple or equivalent to, or valid leasehold interests in, or easements or other limited property interests in, all its Real Properties (including all Mortgaged Properties) and has valid title to its personal property and assets, in each case, except for Permitted Liens and except for defects in title that do not materially interfere with its ability to conduct its business as currently conducted or to utilize such properties and assets for their intended purposes and except where the failure to have such title would not reasonably be expected to have, individually or in the aggregate, a Material Adverse Effect. All such properties and assets are free and clear of Liens, other than Permitted Liens or Liens arising by operation of law. The Equity Interests of the Borrower owned by Holdings (prior to a Qualified IPO) are free and clear of Liens, other than Liens permitted by Article VIA.
(b) The Borrower and each of the Subsidiaries has complied with all material obligations under all leases to which it is a party, except where the failure to comply would not reasonably be expected to have Material Adverse Effect, and all such leases are in full force and effect, except leases in respect of which the failure to be in full force and effect would not reasonably be expected to have a Material Adverse Effect.
(c) As of the Closing Date, none of the Borrower and the Subsidiaries has received any written notice of any pending or contemplated condemnation proceeding affecting any material portion of the Mortgaged Properties or any sale or disposition thereof in lieu of condemnation that remains unresolved as of the Closing Date, except as set forth on Schedule 3.07(c).
(d) As of the Closing Date, none of the Borrower and its Subsidiaries is obligated under any right of first refusal, option or other contractual right to sell, assign or otherwise Dispose of any Mortgaged Property or any interest therein, except as permitted under Section 6.02 or 6.05 or as would not reasonably be expected to have a Material Adverse Effect.
(e) Schedule 1.01(E) lists each Material Real Property owned by any Loan Party as of the Closing Date.
VACANT POSSESSION The Purchaser after the payment of the TPP shall at his own costs and expenses take possession of the Property without any obligation on the part of the Assignee/Bank to give vacant possession and the Purchaser is PROHIBITED from entering upon the Property or take possession of the Property prior to the settlement of the balance purchase price and/or late payment interest (if any).
Documents, Records and Funds in Possession of the Master Servicer to be Held for the Trustee. The Master Servicer shall account fully to the Trustee for any funds it receives or otherwise collects as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, the Collection Account, Distribution Account, or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment, or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
NO VACANT POSSESSION 14.1 The Purchaser shall upon full payment of the Balance Purchase Price together with all interest on late payment (if any) be entitled at his own costs and expenses to take possessions of the Property.
14.2 The Bank shall not be under any obligation whatsoever to deliver vacant possession of the Property or to forward to the Purchaser or any party any keys to the Property.
14.3 The Property is sold subject to all existing easements, leases, tenancies, occupiers, charges, caveats, previous Sale and Purchase, previous assignment, covenants, liabilities subsisting thereon or thereover and the Purchaser shall be deemed to have full knowledge of the state and condition of the Property.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
