TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed.
2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County.
2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract.
2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief.
2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
COMMENCEMENT AND TERMINATION 10.1 This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein.
10.2 This Agreement shall terminate without penalty:
a. As to any Participating Fund, at the option of Insurance Company or the Participating Fund at any time from the date hereof upon 180 days' notice, unless a shorter time is agreed to by the respective Participating Fund and Insurance Company;
b. As to any Participating Fund, at the option of Insurance Company, if shares of that Participating Fund are not reasonably available to meet the requirements of the Contracts as determined by Insurance Company. Prompt notice of election to terminate shall be furnished by Insurance Company, said termination to be effective ten days after receipt of notice unless the Participating Fund makes available a sufficient number of shares to meet the requirements of the Contracts within said ten-day period;
c. As to a Participating Fund, at the option of Insurance Company, upon the institution of formal proceedings against that Participating Fund by the Commission, National Association of Securities Dealers or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in Insurance Company's reasonable judgment, materially impair that Participating Fund's ability to meet and perform the Participating Fund's obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by Insurance Company with said termination to be effective upon receipt of notice;
d. As to a Participating Fund, at the option of each Participating Fund, upon the institution of formal proceedings against Insurance Company by the Commission, National Association of Securities Dealers or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in the Participating Fund's reasonable judgment, materially impair Insurance Company's ability to meet and perform Insurance Company's obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by such Participating Fund with said termination to be effective upon receipt of notice;
e. As to a Participating Fund, at the option of that Participating Fund, if the Participating Fund shall determine, in its sole judgment reasonably exercised in good faith, that Insurance Company has suffered a material adverse change in its business or financial condition or is the subject of material adverse publicity and such material adverse change or material adverse publicity is likely to have a material adverse impact upon the business and operation of that Participating Fund or Dreyfus, such Participating Fund shall notify Insurance Company in writing of such determination and its intent to terminate this Agreement, and after considering the actions taken by Insurance Company and any other changes in circumstances since the giving of such notice, such determination of the Participating Fund shall continue to apply on the sixtieth (60th) day following the giving of such notice, which sixtieth day shall be the effective date of termination;
f. As to a Participating Fund, upon termination of the Investment Advisory Agreement between that Participating Fund and Dreyfus or its successors unless Insurance Company specifically approves the selection of a new Participating Fund investment adviser. Such Participating Fund shall promptly furnish notice of such termination to Insurance Company;
g. As to a Participating Fund, in the event that Participating Fund's shares are not registered, issued or sold in accordance with applicable federal law, or such law precludes the use of such shares as the underlying investment medium of Contracts issued or to be issued by Insurance Company. Termination shall be effective immediately as to that Participating Fund only upon such occurrence without notice;
h. At the option of a Participating Fund upon a determination by its Board in good faith that it is no longer advisable and in the best interests of shareholders of that Participating Fund to continue to operate pursuant to this Agreement. Termination pursuant to this Subsection (h) shall be effective upon notice by such Participating Fund to Insurance Company of such termination;
i. At the option of a Participating Fund if the Contracts cease to qualify as annuity contracts or life insurance policies, as applicable, under the Code, or if such Participating Fund reasonably believes that the Contracts may fail to so qualify;
j. At the option of any party to this Agreement, upon another party's breach of any material provision of this Agreement;
k. At the option of a Participating Fund, if the Contracts are not registered, issued or sold in accordance with applicable federal and/or state law; or
l. Upon assignment of this Agreement, unless made with the written consent of every other non-assigning party. Any such termination pursuant to Section 10.2a, 10.2d, 10.2e, 10.2f or 10.2k herein shall not affect the operation of Article V of this Agreement. Any termination of this Agreement shall not affect the operation of Article IX of this Agreement.
10.3 Notwithstanding any termination of this Agreement pursuant to Section 10.2 hereof, each Participating Fund and Dreyfus may, at the option of the Participating Fund, continue to make available additional shares of that Participating Fund for as long as the Participating Fund desires pursuant to the terms and conditions of this Agreement as provided below, for all Contracts in effect on the effective date of termination of this Agreement (hereinafter referred to as "Existing Contracts"). Specifically, without limitation, if that Participating Fund and Dreyfus so elect to make additional Participating Fund shares available, the owners of the Existing Contracts or Insurance Company, whichever shall have legal authority to do so, shall be permitted to reallocate investments in that Participating Fund, redeem investments in that Participating Fund and/or invest in that Participating Fund upon the making of additional purchase payments under the Existing Contracts. In the event of a termination of this Agreement pursuant to Section 10.2 hereof, such Participating Fund and Dreyfus, as promptly as is practicable under the circumstances, shall notify Insurance Company whether Dreyfus and that Participating Fund will continue to make that Participating Fund's shares available after such termination. If such Participating Fund shares continue to be made available after such termination, the provisions of this Agreement shall remain in effect and thereafter either of that Participating Fund or Insurance Company may terminate the Agreement as to that Participating Fund, as so continued pursuant to this Section 10.3, upon prior written notice to the other party, such notice to be for a period that is reasonable under the circumstances but, if given by the Participating Fund, need not be for more than six months.
10.4 Termination of this Agreement as to any one Participating Fund shall not be deemed a termination as to any other Participating Fund unless Insurance Company or such other Participating Fund, as the case may be, terminates this Agreement as to such other Participating Fund in accordance with this Article X.
