Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans; the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
COMMENCEMENT/EXPIRATION DATE This agreement is executed as of the date of the last signature and is effective through at which time it will expire. The expiration date is the final date for completion of all work activities under this agreement.
Commencement Date The Subcontractor shall be permitted to begin the Services on ______________________, 20____ (“Commencement Date”).
Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Commencement Date and Term 1.1 This Agreement shall come into force on [insert date] (the “Commencement Date”) and, subject to paragraph 1.2 below, shall continue in full force and effect until [insert date] OR [until all Services have been completed and all Deliverables have been delivered to the British Council’s satisfaction as set out in Schedule 2 (Terms of Reference)] (the “Term”). 1.2 Notwithstanding anything to the contrary elsewhere in this Agreement, the British Council shall be entitled to terminate this Agreement by serving not less than [insert number of days] days’ written notice on the Supplier.
Term Commencement Date The date that the Premises are Ready For Occupancy (as defined in Exhibit D attached hereto), which Term Commencement Date is anticipated to be August 1, 2015. In the event Landlord fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before November 1, 2015 ("First Outside Date") as such First Outside Date shall be extended due to Force Majeure delays and Tenant Delays, Tenant will be entitled to one day of free Monthly Base Rent, to be applied after the Term Commencement Date, for each day after such First Outside Date that the Premises are not delivered to Tenant as required hereunder. In the event fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before December 1, 2015 ("Second Outside Date"), as such Second Outside Date shall be deemed extended due to Force Majeure delays and Tenant Delays, Tenant may terminate this Lease by delivery of written notice to Landlord no later than that date which is five (5) business days after such Second Outside Date, in which case Landlord will immediately refund all amounts paid by Tenant pursuant to this Lease and Tenant shall have no further obligations to Landlord pursuant to this Lease except for those obligations which expressly survive the expiration or sooner termination of this Lease.
Commencement of the Offer Provided that this Agreement shall not have been terminated in accordance with Article 9, as promptly as practicable after the Agreement Date (but in no event more than ten (10) Business Days after the Agreement Date), Purchaser shall (and Parent shall cause Purchaser to) commence (within the meaning of Rule 14d-2 under the Exchange Act) the Offer.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.
Vesting Commencement Date Exercise Price per Share: Total Number of Shares Subject to the Option: Total Exercise Price: Expiration Date:
Acceptance Period For all Services provided under this Agreement, Vendor grants to Citizens a thirty (30) calendar day acceptance period ("Acceptance Period") commencing on the date completed Services are delivered to Citizens. Citizens shall have the right to reject the Services, in whole or in part, during the Acceptance Period for Vendor’s failure to meet the specifications associated with the delivered Services, with such determination to be made in Citizens’ reasonable judgment. At the end of the Acceptance Period, if Citizens has not rejected the Services, the Services shall be deemed to be accepted by Citizens; provided, however, that Citizens’ acceptance of the Services shall not be deemed a waiver of any of Citizens’ warranty rights as expressly provided in this Agreement.
