Product Complaints Subdistributor shall promptly notify Distributor of (but in no event later than 24 hours after receipt), and provide, upon Distributor’s request, reasonable assistance to address and investigate, any complaint or adverse claim about any Product or its use of which Subdistributor becomes aware;
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Tests and Preclinical and Clinical Trials The preclinical studies and clinical trials conducted by or, to the Company’s knowledge, on behalf of the Company, that are described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, as applicable, and are intended to be submitted to the U.S. Food and Drug Administration (the “FDA”) or other comparable government entities, were and, if still ongoing, are being conducted in all material respects in accordance with experimental protocols, procedures and controls pursuant to accepted professional scientific standards and all Authorizations and Applicable Laws, including, without limitation, current Good Clinical Practices and Good Laboratory Practices and any applicable rules and regulations of the jurisdiction in which such trials and studies are being conducted; the descriptions of the results of such studies and trials contained in the Registration Statement, the Pricing Disclosure Package and the Prospectus are, to the Company’s knowledge, accurate and complete in all material respects and fairly present the data derived from such studies and trials; except to the extent disclosed in the Registration Statement, the Pricing Disclosure Package and the Prospectus, the Company is not aware of any studies or trials, the results of which the Company believes reasonably call into question the study or trial results described or referred to in the Registration Statement, the Pricing Disclosure Package and the Prospectus when viewed in the context in which such results are described and the clinical stage of development; and, except to the extent disclosed in the Registration Statement, the Pricing Disclosure Package or the Prospectus, the Company has not received any written notices or written correspondence from the FDA or any governmental entity requiring the termination or suspension of any preclinical studies or clinical trials conducted by or on behalf of the Company, other than ordinary course communications with respect to modifications in connection with the design and implementation of such trials, copies of which communications have been made available to you.
Clinical 1.1 Provides comprehensive evidence based nursing care and individual case management to a specific group of patients/clients including assessment, intervention and evaluation.
1.2 Undertakes clinical shifts at the direction of senior staff and the Nursing Director including participation on the on-call/after-hours/weekend roster if required.
1.3 Responsible and accountable for patient safety and quality of care through planning, coordinating, performing, facilitating, and evaluating the delivery of patient care relating to a particular group of patients, clients or staff in the practice setting.
1.4 Monitors, reviews and reports upon the standard of nursing practice to ensure that colleagues are working within the scope of nursing practice, following appropriate clinical pathways, policies, procedures and adopting a risk management approach in patient care delivery.
1.5 Participates in xxxx rounds/case conferences as appropriate.
1.6 Educates patients/carers in post discharge management and organises discharge summaries/referrals to other services, as appropriate.
1.7 Supports and liaises with patients, carers, colleagues, medical, nursing, allied health, support staff, external agencies and the private sector to provide coordinated multidisciplinary care.
1.8 Completes clinical documentation and undertakes other administrative/management tasks as required.
1.9 Participates in departmental and other meetings as required to meet organisational and service objectives.
1.10 Develops and seeks to implement change utilising expert clinical knowledge through research and evidence based best practice.
1.11 Monitors and maintains availability of consumable stock.
1.12 Complies with and demonstrates a positive commitment to Regulations, Acts and Policies relevant to nursing including the Code of Ethics for Nurses in Australia, the Code of Conduct for Nurses in Australia, the National Competency Standards for the Registered Nurse and the Poisons Act 2014 and Medicines and Poisons Regulations 2016.
1.13 Promotes and participates in team building and decision making.
1.14 Responsible for the clinical supervision of nurses at Level 1 and/or Enrolled Nurses/ Assistants in Nursing under their supervision.
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
PRICE LISTS AND PRODUCT INFORMATION Contractors should provide an electronic version of the proposed price list in an Excel format or pdf on a jump drive. Also provide a dealer list, if applicable in an Excel format with "read and write" capabilities on the same jump drive. No costs or expenses associated with providing this information in the required format shall be charged to the State of Arkansas. At the time of contract renewal contractor will furnish OSP with an updated dealer list and published price list.
Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
