Completion of Study Following Receipt of Objection Notice Sample Clauses

Completion of Study Following Receipt of Objection Notice. In the event of receipt by the Contractor of an Objection Notice in accordance with Clause 7.5, the Contractor shall: (a) take due account of all Defects, irrespective of their extent or nature, and other matters raised in the Objection Notice; (b) as soon as reasonably practicable but no later as mentioned in the Objection Notice and in the Agreement, correct such Defects and deficiencies, irrespective of their extent or nature, and complete the Works indicated in the Objection Notice so as to comply in all material respects with the requirements of this Agreement and Applicable Law; and (c) issue to the Principal a second Provisional Completion Note substantially in the form of Annex F: Form of Provisional Completion Note. The second Provisional Completion Note issued in accordance with Clause 7.6(c) shall include the Deliverable and adequate supporting Documentation and information relevant to the Study Milestone attained and/or Deliverable completed. In the event no reasons for objection to the second Provisional Completion Note exist, the Principal shall, within reasonable time following receipt of the second Provisional Completion Note, issue a Provisional Acceptance Note in the form of Annex G: Form of Provisional Acceptance Note and, subject to the provisions of Clauses 2.5 and 9.1(b) of this Agreement, the date of the Provisional Acceptance Note shall constitute “Completion Date” with respect to the relevant Study Milestone and/or Deliverable. In the event the Principal objects to the issuance of a Provisional Completion Note in accordance with this Clause 7.6, it shall give the second Objection Notice to the Contractor in the previously mentioned order. For the avoidance of any doubt, the giving by the Principal of any Objection Notice under Clause 7.5 or second Objection Notice under this Clause 7.6 shall be without prejudice to and shall not relieve the Contractor from the obligation to pay any contractual penalty in accordance with the provisions of Clause 10.2 or to pay Damages in accordance with the provisions Clause 10.3 of this Agreement.
Sample 1Sample 2See All (7)
AutoNDA by SimpleDocs
Completion of Study Following Receipt of Objection Notice. In the event of receipt by the Contractor of an Objection Notice in accordance with Clause 7.5, the Contractor shall: (a) take due account of all Defects, irrespective of their extent or nature, and other matters raised in the Objection Notice; (b) as soon as reasonably practicable but no later as mentioned in the Objection Notice and in the Agreement, correct such Defects and deficiencies, irrespective of their extent or nature, and complete the Works indicated in the Objection Notice so as to comply in all material respects with the requirements of this Agreement and Applicable Law; and (c) issue to the Principal a second Provisional Completion Note substantially in the form of
Sample 1
Completion of Study Following Receipt of Objection Notice. In the event of receipt by the Contractor of an Objection Notice in accordance with Clause 7.5, the Contractor shall: (a) take due account of all Defects, irrespective of their extent or nature, and other matters raised in the Objection Notice; (b) as soon as reasonably practicablebut no later as mentioned in the Objection Notice, correct such Defects and deficiencies, irrespective of their extent or nature, and complete the Works indicated in the Objection Notice so as to comply in all material respects with the requirements of this Agreement; and (c) issue to the Principal a second Provisional Completion Note substantially in the form of Annex F (Form of Provisional Completion Note). The second Provisional Completion Note issued in accordance with Clause 7.6(c) shall include the Deliverable and adequate supporting documentation relevant to the Study Milestone attained and/or Deliverable completed. In the event no reasons for objection to the second Provisional Completion Note exist, the Principal shall, within reasonable time following receipt of the second Provisional Completion Note, issue a Provisional Acceptance Note in the form of Annex G (Form of Provisional Acceptance Note) and, subject to the provisions of Clauses 2.5 and 9.1(b) of this Agreement, the date of the Provisional Acceptance
Sample 1

Related to Completion of Study Following Receipt of Objection Notice

  • Certificate of Completion The Interconnection Customer shall provide the EDC with a completed copy of the Interconnection Agreement Certificate of Completion, including evidence of the electrical inspection performed by the local authority having jurisdiction. The evidence of completion of the electrical inspection may be provided on inspection forms used by local inspecting authorities. The Interconnection request shall not be finally approved until the EDC’s representative signs the Interconnection Agreement Certificate of Completion.

  • Notice of Objection Contractor may object to any action taken by NYSERDA pursuant to this Exhibit that prevents the commencement of the time in which interest will be paid by submitting a written notice of objection to NYSERDA. Such notice shall be signed and dated and concisely and clearly set forth the basis for the objection and be addressed to the Vice President, New York State Energy Research and Development Authority, at the notice address set forth in Exhibit B to this Agreement. The Vice President of NYSERDA, or his or her designee, shall review the objection for purposes of affirming or modifying NYSERDA‘s action. Within fifteen (15) working days of the receipt of the objection, the Vice President, or his or her designee, shall notify the Contractor either that NYSERDA‘s action is affirmed or that it is modified or that, due to the complexity of the issue, additional time is needed to conduct the review; provided, however, in no event shall the extended review period exceed thirty (30) working days.

  • Certificate of Substantial Completion The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the City when construction is sufficiently complete, in accordance with the Contract Documents, so the City of Roanoke, Virginia (City or Owner) can occupy or utilize the Work or designated portion thereof for the use for which it is intended, as expressed in the Contract Documents. ITB NO.: PROJECT: CONTRACTOR: PROJECT OR DESIGNATED PORTION SHALL INCLUDE: The Work or portion thereof designated above performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial Completion of the Project or portion thereof designated above is hereby established as . The City will assume possession thereof at a.m./p.m. on that date. A list of items ("punch list"), prepared by the A/E and/or Director, Department of Public Works, to be completed or corrected by the Contractor, is attached hereto. The failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. The Contractor will complete any portion of the Work that is not substantially complete and will complete or correct the work on the punch list in accordance with the Contract Documents. The establishment of a date of substantial completion and/or the acceptance of the Work or designated portion thereof does not relieve the Contractor of any responsibility for any faulty materials or workmanship or operate to relieve the Contractor or its Surety from any obligation under the Contract with the City or the Performance Bond or Labor and Material Payment Bond. This Certificate is subject to the terms and conditions of the Contract Documents, including but not limited to Section 20.8 of the General Conditions. Contractor By Date City of Roanoke, Virginia City By Date CITY OF ROANOKE, VIRGINIA AFFIDAVIT OF PAYMENT OF CLAIMS By: This day personally appeared before me, , and, being by me first duly sworn states that all subcontractors and suppliers of labor and materials have been paid all sums due them for work performed or materials furnished in the performance of the Contract between the City of Roanoke, Virginia, and ,Contractor, dated , 20 , for or arrangements have been made by the Contractor satisfactory to such subcontractors and suppliers with respect to the payment of such sums as may be due from the Contractor to the subcontractors and suppliers. COMMONWEALTH OF VIRGINIA CITY/COUNTY OF I, , a Notary Public in and for the Commonwealth of Virginia, do hereby certify that , whose name is signed to the foregoing, has subscribed, sworn to and acknowledged the same before me this day of , 20 . Seal: Notary Public Registration #: My Commission Expires:

  • Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.

  • Response to Objections Each Party retains the right to respond to any objection raised by a Participating Class Member, including the right to file responsive documents in Court no later than five court days prior to the Final Approval Hearing, or as otherwise ordered or accepted by the Court.

  • Notice of Completion The Interconnection Customer shall notify the Transmission Provider and the Interconnected Transmission Owner in writing when it has completed construction of (i) the Customer Facility;

  • Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.

  • Satisfactory Completion of Due Diligence The Company and the Shareholders shall have completed their legal, accounting and business due diligence of the Parent and the results thereof shall be satisfactory to the Company and the Shareholders in their sole and absolute discretion.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

  • Final Completion The full and final completion of all Work in accordance with the Contract Documents.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!