Intellectual Property Indemnity To the fullest extent permitted by law, Contractor shall defend, indemnify, and hold Enterprise Services and any Purchaser and their employees and agents harmless from against any and all Claims resulting from allegations of infringement of any patents, copyrights, trade secret, or similar intellectual property rights covering the Goods and/or Services provided, or the use of the Goods and/or Services under this Contract. If Purchaser’s use of Goods and/or Services provided by Contractor is enjoined based on an intellectual property infringement Claim, Contractor shall, at its own expense, either procure for Purchaser the right to continue using the Goods and/or Services or, after consulting with Purchaser and obtaining Purchaser’s consent, replace or modify the Goods and/or Services with substantially similar and functionally equivalent non-infringing Goods and/or Services.
Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Intellectual Property Indemnification Supplier agrees to defend, indemnify, and hold harmless DXC and its affiliates, subsidiaries, assigns, agents, subcontractors, distributors and customers (collectively “Indemnitees”) from and against all claims, losses, demands, fees, damages, liabilities, costs, expenses, obligations, causes of action, suits, or injuries, of any kind or nature, arising from: (i) any claim that Supplier’s Products or Services, or the use, sale or importation of them, infringes any intellectual property right. Without limiting the foregoing, Supplier will pay all costs, damages and expenses (including reasonable attorneys’ fees) incurred by DXC and/or its Indemnitees and will pay any award with respect to any such claim or agreed to in settlement of that claim.
General Conditions Applicable to Insurance All policies of insurance required by this section shall comply with the following requirements:
Claims relating to Intellectual Property Rights 29.1. The Contractor must not infringe any Intellectual Property Rights of any third party in providing the Services or otherwise performing its obligations under the Framework Agreement and must ensure that the provision of the Services and the use or possession of the Deliverables does not infringe such Intellectual Property Rights.
29.2. The Contractor must promptly notify the Authority if any claim or demand is made or action brought against the Contractor for infringement or alleged infringement of any Intellectual Property Right which may affect the use or possession of the Deliverables or which may affect the provision of the Services.
29.3. Where a claim to which this clause applies is made, the Contractor must, at its expense, use its best endeavours to:
29.3.1. modify the Services or Deliverables or substitute alternative Services or Deliverables (in any case without reducing performance or functionality) so as to avoid the infringement or alleged infringement of the Intellectual Property Rights; or
29.3.2. procure the grant of a licence or licences from the pursuer, claimant or complainer, on terms acceptable to the Authority, so as to avoid the infringement or alleged infringement of the Intellectual Property Rights of the pursuer, claimant or complainer.
29.4. The Contractor must not without the consent of the Authority make any admissions which may be prejudicial to the defence or settlement of any claim to which this clause applies.
Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim
Conditions Applicable to Insurance All policies of insurance required by this solicitation or any Contract resulting from this solicitation must meet the following requirements:
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Conditions Precedent to Indemnification It shall be a condition precedent to the obligation of the Receiver to indemnify any Person pursuant to this Article XII that such Person shall, with respect to any claim made or threatened against such Person for which such Person is or may be entitled to indemnification hereunder:
(a) give written notice to the Regional Counsel (Litigation Branch) of the Corporation in the manner and at the address provided in Section 13.7 of such claim as soon as practicable after such claim is made or threatened; provided, that notice must be given on or before the date which is six (6) years from the date of this Agreement;
(b) provide to the Receiver such information and cooperation with respect to such claim as the Receiver may reasonably require;
(c) cooperate and take all steps, as the Receiver may reasonably require, to preserve and protect any defense to such claim;
(d) in the event suit is brought with respect to such claim, upon reasonable prior notice, afford to the Receiver the right, which the Receiver may exercise in its sole discretion, to conduct the investigation, control the defense and effect settlement of such claim, including without limitation the right to designate counsel and to control all negotiations, litigation, arbitration, settlements, compromises and appeals of any such claim, all of which shall be at the expense of the Receiver; provided, that the Receiver shall have notified the Person claiming indemnification in writing that such claim is a claim with respect to which the Person claiming indemnification is entitled to indemnification under this Article XII;
(e) not incur any costs or expenses in connection with any response or suit with respect to such claim, unless such costs or expenses were incurred upon the written direction of the Receiver; provided, that the Receiver shall not be obligated to reimburse the amount of any such costs or expenses unless such costs or expenses were incurred upon the written direction of the Receiver;
(f) not release or settle such claim or make any payment or admission with respect thereto, unless the Receiver consents in writing thereto, which consent shall not be unreasonably withheld; provided, that the Receiver shall not be obligated to reimburse the amount of any such settlement or payment unless such settlement or payment was effected upon the written direction of the Receiver; and
(g) take reasonable action as the Receiver may request in writing as necessary to preserve, protect or enforce the rights of the indemnified Person against any Primary Indemnitor.
