Conditions to Funding the Construction Allowance Sample Clauses

Open Split View

Download

Share

Cite

Conditions to Funding the Construction Allowance. Without limiting other Conditions to Advances already set forth in the Lease, it is agreed that:

Sample 1

Save

Copy

Related to Conditions to Funding the Construction Allowance

• Conditions to Funding The obligations of the Lenders to make any Credit Extension hereunder on the Funding Date are subject to the satisfaction of the following conditions: (a) The Funding Date shall be a Business Day on or before the Long StopLongstop Date. (b) The Administrative Agent shall have received, on behalf of itself and the Lenders, a legal opinion of Ropes & Xxxx International LLP, New York counsel for the Borrower, in form reasonably acceptable to the Administrative Agent (i) dated the Funding Date, (ii) addressed to the Administrative Agent, the Security Agent and the Lenders and (iii) covering such other matters relating to the Loan Documents and the Existing Transactions as the Administrative Agent shall reasonably request, and the Borrower hereby requests such counsel to deliver such opinions. (c) The Administrative Agent shall have received: (i) A copy of the Organization Documents of each Loan Party. (ii) In respect of each Loan Party incorporated or established and/or having its registered office in the United States, a certificate of good standing in respect of such Loan Party. (iii) A copy of a resolution of the board or, if applicable, a committee of the board, of directors of each Loan Party (A) approving the terms of, and the transactions contemplated by, the Loan Documents to which it is a party and resolving that it execute, deliver and perform the Loan Documents to which it is a party; (B) authorising a specified person or persons to execute the Loan Documents to which it is a party on its behalf; and (C) authorising a specified person or persons, on its behalf, to sign and/or deliver all documents and notices (including, if relevant, any Borrowing Request) to be signed and/or delivered by it under or in connection with the Loan Documents to which it is a party. (iv) A specimen of the signature of each person authorised by the resolution in relation to the Loan Documents and related documents. (v) A secretary’s certificate of each Loan Party in a form reasonably satisfactory to the Administrative Agent. (d) [Reserved]. (e) The Administrative Agent shall have received, at least three Business Days prior to the Funding Date, all documentation and other information required by regulatory authorities under applicable “know your customer” and anti-money laundering rules and regulations, including the USA PATRIOT Act, that has been reasonably requested by the Initial Lenders at least ten days prior to the Funding Date. (f) The Administrative Agent shall have received the Loan Escrow Agreement duly executed and delivered (or counterparts hereof) by the Borrower. (g) A certificate from the chief financial officer (or other Responsible Officer) of the Borrower, substantially in the form attached as Exhibit I hereto, certifying that the Borrower is Solvent. (h) Each Major Representation is true in all material respects. (i) Solely if the Closing Date has not occurred on the Funding Date, the Administrative Agent shall have received the Escrow Guarantee Agreement duly executed and delivered (or counterparts thereof) by the Escrow Guarantor, the Borrower and the other parties thereto.

• Conditions to Each Party’s Obligation to Effect the Closing The respective obligation of each party to effect the Closing shall be subject to the satisfaction or waiver at or prior to the Effective Time of the following conditions:

• Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

• Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

• RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.

• Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

• Additional Conditions to Obligation of the Company The obligation of the Company to effect the Merger is also subject to the following conditions:

• CONDITIONS TO EACH BUYER’S OBLIGATION TO PURCHASE The obligation of each Buyer hereunder to purchase the Notes and Warrants at the Closing is subject to the satisfaction, at or before the Closing Date of each of the following conditions, provided that these conditions are for such Buyer’s sole benefit and may be waived by such Buyer at any time in its sole discretion: a. The Company shall have executed this Agreement and the Registration Rights Agreement, and delivered the same to the Buyer. b. The Company shall have delivered to such Buyer duly executed Notes (in such denominations as the Buyer shall request) and Warrants in accordance with Section 1(b) above. c. The Irrevocable Transfer Agent Instructions, in form and substance satisfactory to a majority-in-interest of the Buyers, shall have been delivered to and acknowledged in writing by the Company’s Transfer Agent. d. The representations and warranties of the Company shall be true and correct in all material respects as of the date when made and as of the Closing Date as though made at such time (except for representations and warranties that speak as of a specific date) and the Company shall have performed, satisfied and complied in all material respects with the covenants, agreements and conditions required by this Agreement to be performed, satisfied or complied with by the Company at or prior to the Closing Date. The Buyer shall have received a certificate or certificates, executed by the chief executive officer of the Company, dated as of the Closing Date, to the foregoing effect and as to such other matters as may be reasonably requested by such Buyer including, but not limited to certificates with respect to the Company’s Certificate of Incorporation, By-laws and Board of Directors’ resolutions relating to the transactions contemplated hereby. e. No litigation, statute, rule, regulation, executive order, decree, ruling or injunction shall have been enacted, entered, promulgated or endorsed by or in any court or governmental authority of competent jurisdiction or any self-regulatory organization having authority over the matters contemplated hereby which prohibits the consummation of any of the transactions contemplated by this Agreement. f. No event shall have occurred which could reasonably be expected to have a Material Adverse Effect on the Company. g. The Conversion Shares and Warrant Shares shall have been authorized for quotation on the OTCBB and trading in the Common Stock on the OTCBB shall not have been suspended by the SEC or the OTCBB. h. The Buyer shall have received an opinion of the Company’s counsel, dated as of the Closing Date, in form, scope and substance reasonably satisfactory to the Buyer and in substantially the same form as Exhibit “D” attached hereto. i. The Buyer shall have received an officer’s certificate described in Section 3(c) above, dated as of the Closing Date.

• Conditions to Xxxxx’x Obligations The obligations of Xxxxx hereunder with respect to a Placement will be subject to the continuing accuracy and completeness of the representations and warranties made by the Company herein, to the due performance by the Company of its obligations hereunder, to the completion by Xxxxx of a due diligence review satisfactory to Xxxxx in its reasonable judgment, and to the continuing satisfaction (or waiver by Xxxxx in its sole discretion) of the following additional conditions:

• General Conditions Costs Contractor is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from Owner through Substantial Completion of the Project, plus 30 calendar days. Contractor is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion, plus 30 calendar days, must be approved in advance by Owner. Allowable General Conditions items are identified below and in Exhibit “D” attached to this Agreement. These items shall be included in the General Conditions Cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the Schedule of Values. Items not specifically included below or in Exhibit “D” will not be allowed as General Condition Costs.