Consent to Occupancy dated November 8, 2005, by and among Lakewood Property Trust (“Landlord”), The Austin Diagnostic Clinic, P.A. (“Tenant”) and Clinic Pathology Laboratories (“Occupant”). INDEX Lease Lakewood A Grande Communications
Consent to Occupancy Sample Clauses
Related to Consent to Occupancy
Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.
USE AND OCCUPANCY Tenant covenants that no waste shall be committed upon or to the Leased Property; that the Leased Property shall be used for the purpose herein above stated, and shall not be used or permitted to be used for any other purpose; that the Leased Property shall not be used for any unlawful purpose and no violations of law or ordinance shall be committed thereon; that no intoxicating beverages shall be sold, served or stored illegally upon or from the Leased Property; and that nothing shall be done or suffered or any substance kept on the Leased Property which will operate to increase the fire hazard or to cause the insurance rates thereon to be increased. Tenant shall not abuse walls, ceilings, partitions, floors, wood, stone and brick, and iron work; nor use plumbing and electrical wiring for any purpose other than that for which constructed; nor create, maintain, or permit a nuisance therein; nor do any act tending to injure the reputation of the Park. Tenant shall not perform any acts nor carry on any practices which may injure the Leased Property or be a nuisance or menace to other tenants in the Park, and shall store all trash and garbage within the Leased Property, or within containers provided for regular city pickup. If the amount of trash and garbage is too excessive for regular city pickup, Tenant will arrange for pickup and cartage of all excess trash and garbage at Tenant’s expense. Tenant shall not burn any trash or garbage at any time in or about the Leased Property or anywhere else in the Park; provided, however, that Landlord may in its sole discretion permit the burning of trash on the Leased Property or incinerators to be furnished by Tenant and approved by Landlord. Tenant shall at all times during the Lease Term comply with all statutes, municipal and police regulations, and ordinances of Federal, State, City and County governments and agencies or other public authority directed against or in any way affecting the Leased Property or Tenant’s business conducted therein. Tenant shall not permit (a) any release of any hazardous substance from the Leased Property; (b) any unlawful, harmful or improper discharge from the Leased Property into the surrounding atmosphere or into the sewers, drains and waterways on or adjacent to the Leased Property, or the groundwater thereunder; (c) any harmful or improper disposal of liquid or solid waste (hazardous or otherwise) generated on, stored at or transported from the Leased Property. As used in this Section, the terms "hazardous substance," "release" and "removal" shall have the same meaning and definition as set forth in paragraphs (14), (22) and (23), respectively, of 42 U.S.C. § 9601 and in I.C. 13-7-8.7-1: provided, however, that the term "hazardous substance" as used herein also shall include "hazardous waste" (as defined in paragraph (5) of 42 U.S.C. § 6903) and "petroleum" (as defined in paragraph (8) of 42 U.S.C. § 6991).
Completion of Landlord’s Work Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises and shall obtain a certificate or temporary certificate of occupancy (or an equivalent approval) for the Premises permitting lawful occupancy of the Premises during the Term (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Premises not relating to Landlord’s Work)(“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to Landlord’s Work; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments in accordance with good design, engineering, and construction practices for field deviations or conditions encountered during the construction of Landlord’s Work.
Landlord’s Consent Required Subject to the remaining provisions of this Article 11, but notwithstanding anything to the contrary contained elsewhere in this Lease, Tenant shall not assign, transfer or encumber any interest in this Lease (either absolutely or collaterally) or sublease or allow any third party to use any portion of the Premises (collectively or individually, a “Transfer”) without the prior written consent of Landlord, which consent shall not be unreasonably withheld. Without limitation, Tenant agrees that Landlord’s consent shall not be considered unreasonably withheld if: (1) the proposed transferee’s financial condition does not meet the criteria Landlord uses to select Building tenants having similar leasehold obligations; (2) the proposed transferee is a governmental organization or present occupant of the Property, or Landlord is otherwise engaged in lease negotiations with the proposed transferee for other premises in the Property; (3) any uncured event of default exists under this Lease (or a condition exists which, with the passage of time or giving of notice, would become an event of default); (4) any portion of the Building or Premises would likely become subject to additional or different Laws as a consequence of the proposed Transfer; (5) the proposed transferee’s use of the Premises conflicts with the Permitted Use or any exclusive usage rights granted to any other tenant in the Building; (6) the use, nature, business, activities or reputation in the business community of the proposed transferee (or its principals, employees or invitees) does not meet Landlord’s standards for Building tenants; (7) either the Transfer or any consideration payable to Landlord in connection therewith adversely affects the real estate investment trust qualification tests applicable to Landlord or its Affiliates; or (8) the proposed transferee is or has been involved in litigation with Landlord or any of its Affiliates. Tenant shall not be entitled to receive monetary damages based upon a claim that Landlord unreasonably withheld its consent to a proposed Transfer and Tenant’s sole remedy shall be an action to enforce any such provision through specific performance or declaratory judgment. Any attempted Transfer in violation of this Article is voidable at Landlord’s option.
Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than fifteen (15) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may adversely affect the structural components of the Building or the Systems and Equipment in more than a de minimis manner (e.g., the mere tying into Systems shall not be subject to the sole discretion standard) or which can be seen from outside the Building. Tenant shall pay (i) for Alterations performed by Tenant, Landlord’s reasonable third-party costs incurred in connection with reviewing such Alterations, and (ii) for Alterations for which Tenant has engaged Landlord to supervise and Landlord’s contractors to perform, a supervision fee of two and one-half percent (2.5%) of the total cost of such Alteration (for the avoidance of doubt, the foregoing supervisory fee shall not be due or payable in connection with the Tenant Improvements and the Vivarium improvements and no supervisory fee shall be due or payable in connection with any capital improvements performed by Landlord). Notwithstanding the foregoing, no Landlord approval shall be required (provided advance notice shall be provided to Landlord) for (a) installation, removal or realignment of furniture systems not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to the Systems, (b) Alterations which could not reasonably be expected to affect the structural components of the Building or the Systems and Equipment and which cost less than $150,000 for any one (1) job and no more than $300,000 in the aggregate in any calendar year during the Lease Term (excluding any costs for painting, carpeting, and similar purely cosmetic work), (c) Alterations which do not require a building permit, and (d) merely cosmetic work (such as painting and carpeting). The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.
LESSOR'S CONSENT REQUIRED (a) Lessee shall not voluntarily or by operation of law assign, transfer, mortgage or otherwise transfer or encumber (collectively, "assign") or sublet all or any part of Lessee's interest in this Lease or in the Premises without Lessor's prior written consent given under and subject to the terms of Paragraph 36.
Occupancy The Assuming Institution shall give the Receiver fifteen (15) days’ prior written notice of its intention to vacate prior to vacating any leased Bank Premises with respect to which the Assuming Institution has not exercised the option provided in Section 4.6(b). Any such notice shall be deemed to terminate the Assuming Institution’s option with respect to such leased Bank Premises.
Certificate of Occupancy 16.01 Tenant will at no time use or occupy the Premises in violation of the certificate of occupancy issued for the Building. The statement in this Lease of the nature of the business to be conducted by Tenant shall not be deemed to constitute a representation or guaranty by Landlord that such use is lawful or permissible in the Premises under the certificate of occupancy for the Building.
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Performance of Landlords Work (a) Definition of Landlord’s Work. As used herein, “
