Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Application and Operation of Agreement Table Of Contents
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
Operation of Agreement This Agreement will be effective and binding immediately upon its execution, but, anything in this Agreement to the contrary notwithstanding, this Agreement will not be operative unless and until a Change in Control occurs. Upon the occurrence of a Change in Control at any time during the Term, without further action, this Agreement shall become immediately operative.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
Construction of Provisions Although certain provisions of this Agreement contain express language which precludes the Servicer's recovery of, or reimbursement for, expenses incurred hereunder, no inference to the contrary shall be drawn from absence of such, or similar, language in any other provision hereof regarding expenses.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
COMPLETION OF AGREEMENT This document comprises the entire agreement between the District and the Association in the matters lawfully within the scope of negotiation. Neither party shall have any obligation to meet and negotiate during the term of this agreement.
Conduct of Business and Maintenance of Existence, etc (a) (i) Preserve, renew and keep in full force and effect its corporate existence and (ii) take all reasonable action to maintain all rights, privileges and franchises necessary or desirable in the normal conduct of its business, except, in each case, as otherwise permitted by Section 7.4 and except, in the case of clause (ii) above, to the extent that failure to do so could not reasonably be expected to have a Material Adverse Effect; and (b) comply with all Contractual Obligations and Requirements of Law except to the extent that failure to comply therewith could not, in the aggregate, reasonably be expected to have a Material Adverse Effect.
