Construction Borrow and Disposal Sites Sample Clauses

Construction Borrow and Disposal Sites. Up to ten (10) borings will be drilled to depths between about 50 and 100 feet (about 20 feet below the proposed bottom of the borrow area excavation) in the proposed borrow and disposal area sites. Downhole televiewer surveys shall be performed in up to five (5) borings at the borrow areas. Up to three (3) borings in the borrow areas will be converted to open standpipe piezometers. Consultant shall perform seismic refraction surveys across the proposed borrow and disposal areas. Shallow test pits will also be excavated.
Sample 1
AutoNDA by SimpleDocs

Related to Construction Borrow and Disposal Sites

  • Title, Management and Disposition of REO Property In the event that title to any Mortgaged Property is acquired in foreclosure or by deed in lieu of foreclosure, the deed or certificate of sale shall be taken, pursuant to a limited power of attorney in the form attached hereto as Exhibit H, in the name of the Trustee or its nominee (which in no event shall be the Special Servicer) in trust for the benefit of the Certificateholders, or in the event the Trustee is not authorized or permitted to hold title to real property in the state where the REO Property is located, or would be adversely affected under the “doing business” or tax laws of such state by so holding title, the deed or certificate of sale shall be taken in the name of such Person or Persons as shall be consistent with an Opinion of Counsel obtained by the Special Servicer (with a copy delivered to the Trustee) from any attorney duly licensed to practice law in the state where the REO Property is located. Any such Opinion of Counsel will be deemed a Servicing Advance, reimbursable to the Special Servicer in accordance with Section 3.04. The Person or Persons holding such title other than the Trustee shall acknowledge in writing that such title is being held as nominee for the Trustee. The Special Servicer shall manage, conserve, protect and operate each REO Property for the Trustee solely for the purpose of its prompt disposition and sale. The Special Servicer, either itself or through an agent selected by the Special Servicer, shall manage, conserve, protect and operate the REO Property in the same manner that it manages, conserves, protects and operates other foreclosed property for its own account, and in the same manner that similar property in the same locality as the REO Property is managed. The Special Servicer shall attempt to sell the same (and may temporarily rent the same for a period not greater than one year, except as otherwise provided below) on such terms and conditions as the Special Servicer deems to be in the best interest of the Trustee and the Certificateholders. In the event that the Trust Fund acquires any REO Property in connection with a default or imminent default on a Transferred Mortgage Loan, the Special Servicer shall dispose of such REO Property not later than the end of the third taxable year after the year of its acquisition by the Trust Fund unless the Special Servicer has applied for and received a grant of extension from the Internal Revenue Service (and provide a copy of the same to the Master Servicer and the Trustee) to the effect that, under the REMIC Provisions and any relevant proposed legislation and under applicable state law, the applicable Trust REMIC may hold REO Property for a longer period without adversely affecting the REMIC status of such REMIC or causing the imposition of a federal or state tax upon such REMIC and has notified the Master Servicer and the Trustee of such extension by providing a copy of the application and the grant of such extension to the Trustee and the Master Servicer. If the Special Servicer has received such an extension (and provided a copy of the same to the Master Servicer and the Trustee), then the Special Servicer shall continue to attempt to sell the REO Property for its fair market value for such period longer than three years as such extension permits (the “Extended Period”). If the Special Servicer has not received such an extension and the Special Servicer is unable to sell the REO Property within the period ending three months before the end of such third taxable year after its acquisition by the Trust Fund or if the Special Servicer has received such an extension, and the Special Servicer is unable to sell the REO Property within the period ending three months before the close of the Extended Period, the Special Servicer shall, before the end of the three-year period or the Extended Period, as applicable, (i) purchase such REO Property at a price equal to the REO Property’s fair market value or (ii) auction the REO Property to the highest bidder (which may be the Special Servicer) in an auction reasonably designed to produce a fair price prior to the expiration of the three-year period or the Extended Period, as the case may be. The Trustee shall sign any document reasonably requested by, and at the expense of, the Special Servicer, or take any other action reasonably requested by the Special Servicer which would enable the Special Servicer, on behalf of the Trust Fund, to request such grant of extension. In all cases, the disposition of REO Property shall be carried out by the Special Servicer at such price, and upon such terms and conditions, as the Servicer deems to be in the best interests of the Trust Fund. Notwithstanding any other provisions of this Agreement, no REO Property acquired by the Trust Fund shall be rented (or allowed to continue to be rented) or otherwise used by or on behalf of the Trust Fund in such a manner or pursuant to any terms that would: (i) cause such REO Property to fail to qualify as “foreclosure property” within the meaning of Section 860G(a)(8) of the Code; or (ii) subject any Trust REMIC to the imposition of any federal income taxes on the income earned from such REO Property, including any taxes imposed by reason of Sections 860F or 860G(c) of the Code, unless the Special Servicer has agreed to indemnify and hold harmless the Trust Fund with respect to the imposition of any such taxes. The Special Servicer shall also maintain on each REO Property fire and hazard insurance with extended coverage in amount which is at least equal to the maximum insurable value of the improvements which are a part of such property, liability insurance and, to the extent required and available under the Flood Disaster Protection Act of 1973, as amended, flood insurance in the amount required above. The proceeds of sale of the REO Property shall be promptly deposited in the Custodial Account. As soon as practical thereafter the expenses of such sale shall be paid and the Special Servicer shall reimburse itself for any related unreimbursed Servicing Advances, unpaid Servicing Fees, unreimbursed Monthly Advances made pursuant to this Section or Section 4.03 or the REO Disposition Fee. The Special Servicer shall make advances of all funds necessary for the proper operation, management and maintenance of the REO Property, including the cost of maintaining any hazard insurance pursuant to Section 3.10, such advances to be reimbursed from the disposition or liquidation proceeds of the REO Property. The Special Servicer shall make monthly distributions on each Remittance Date to the Master Servicer of the net cash flow from the REO Property (which shall equal the revenues from such REO Property net of the expenses described in this Section 3.17 and of any reserves reasonably required from time to time to be maintained to satisfy anticipated liabilities for such expenses).

  • Use and Disposition of Collateral None of the Grantors shall make or permit to be made an assignment, pledge or hypothecation of the Collateral or shall grant any other Lien in respect of the Collateral, except as expressly permitted by Section 6.02

  • Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.

  • Replacement of Lost Investments In the event of a loss of Investments for which the Custodian is responsible under the terms of this Agreement, the Custodian shall replace such Investment, or in the event that such replacement cannot be effected, the Custodian shall pay to the Fund the fair market value of such Investment based on the last available price as of the close of business in the relevant market on the date that a claim was first made to the Custodian with respect to such loss, or, if less, such other amount as shall be agreed by the parties as the date for settlement.

  • Title, Conservation and Disposition of REO Property This Section shall apply only to REO Properties acquired for the account of the Trust Fund, and shall not apply to any REO Property relating to a Mortgage Loan which was purchased or repurchased from the Trust Fund pursuant to any provision hereof. In the event that title to any such REO Property is acquired, the deed or certificate of sale shall be issued to the Trustee, or to its nominee, on behalf of the Certificateholders. The Master Servicer, on behalf of the Trust Fund, shall either sell any REO Property within two years after the Trust Fund acquires ownership of such REO Property for purposes of Section 86OG(a)(8) of the Code or, at the expense of the Trust Fund, request an extension of the two-year grace period, more than 60 days before the day on which the two-year grace period would otherwise expire, unless the Master Servicer has delivered to the Trustee an Opinion of Counsel, addressed to the Trustee and the Master Servicer, to the effect that the holding by the Trust Fund of such REO Property subsequent to two years after its acquisition will not result in the imposition on the Trust Fund of taxes on "prohibited transactions" thereof, as defined in Section 86OF of the Code, or cause the Trust Fund to fail to qualify as a REMIC under federal law at any time that any Certificates are outstanding. The Master Servicer shall manage, conserve, protect and operate each REO Property for the Certificateholders solely for the purpose of its prompt disposition and sale in a manner which does not cause such REO Property to fail to qualify as "foreclosure property" within the meaning of Section 86OG(a)(8) or result in the receipt by the Trust Fund of any "income from non- permitted assets" within the meaning of Section 86OF(a)(2)(B) of the Code or any "net income from foreclosure property" which is subject to taxation under the REMIC Provisions. Pursuant to its efforts to sell such REO Property, the Master Servicer shall either itself or through an agent selected by the Master Servicer protect and conserve such REO Property in the same manner and to such extent as is customary in the locality where such REO Property is located and may, incident to its conservation and protection of the interests of the Certificateholders, rent the same, or any part thereof, as the Master Servicer deems to be in the best interest of the Certificateholders for the period prior to the sale of such REO Property. The Master Servicer shall segregate and hold all funds collected and received in connection with the operation of any REO Property separate and apart from its own funds and general assets. The Master Servicer shall deposit, or cause to be deposited, on a daily basis in the Custodial Account all revenues received with respect to the REO Properties, net of any directly related expenses incurred or withdraw therefrom funds necessary for the proper operation, management and maintenance of the REO Property. If as of the date of acquisition of title to any REO Property there remain outstanding unreimbursed Servicing Advances with respect to such REO Property or any outstanding Advances allocated thereto the Master Servicer, upon an REO Disposition, shall be entitled to reimbursement for any related unreimbursed Servicing Advances and any unreimbursed related Advances as well as any unpaid Servicing Fees from proceeds received in connection with the REO Disposition, as further provided in Section 3.15. Subject to the first paragraph of this Section 3.22, the REO Disposition shall be carried out by the Master Servicer at such price and upon such terms and conditions as the Master Servicer shall determine to be in the best economic interest of the Trust Fund. Any REO Disposition shall be for cash only (unless changes in the REMIC Provisions made subsequent to the Startup Day allow a sale for other consideration). The Master Servicer shall deposit the proceeds from the REO Disposition, net of any payment to the Master Servicer as provided above, in the Custodial Account upon receipt thereof for distribution in accordance with Section 4.01, including any such net proceeds which are in excess of the applicable Stated Principal Balance plus all unpaid REO Imputed Interest thereon through the date of the REO Disposition. Notwithstanding the foregoing provisions of this Section 3.22, with respect to any Mortgage Loan as to which the Master Servicer has received notice of, or has actual knowledge of, the presence of any toxic or hazardous substance on the Mortgaged Property, the Master Servicer shall promptly request the Trustee and the Depositor to provide directions and instructions with respect to such Mortgage Loan and shall act in accordance with any such directions and instructions jointly provided by the Trustee and the Depositor. Notwithstanding the preceding sentence of this Section 3.22, with respect to any Mortgage Loan described by such sentence, the Master Servicer shall not, on behalf of the Trustee, either (i) obtain title to the related Mortgaged Property as a result of or in lieu of foreclosure or otherwise, or (ii) otherwise acquire possession of, the related Mortgaged Property, unless (i) the Depositor and the Trustee jointly direct the Master Servicer to take such action and (ii) either (A) the Master Servicer has, at least 30 days prior to taking such action, obtained and delivered to the Depositor an environmental audit report prepared by a Person who regularly conducts environmental audits using customary industry standards or (B) the Depositor has directed the Master Servicer not to obtain an environmental audit report. If the Trustee and the Depositor have not jointly provided directions and instructions to the Master Servicer in connection with any such Mortgage Loan within 30 days of a request by the Master Servicer for such directions and instructions, then the Master Servicer shall take such action as it deems to be in the best economic interest of the Trust Fund (other than proceeding against the Mortgaged Property) and is hereby authorized at such time as it deems appropriate to release such Mortgaged Property from the lien of the related Mortgage. The cost of the environmental audit report contemplated by this Section 3.22 shall be advanced by the Master Servicer as an expense of the Trust Fund, and the Master Servicer shall be reimbursed therefor from the Custodial Account as provided in Section 3.11, any such right of reimbursement being prior to the rights of the Certificateholders to receive any amount in the Custodial Account. If the Master Servicer determines, as described above, that it is in the best economic interest of the Trust Fund to take such actions as are necessary to bring any such Mortgaged Property in compliance with applicable environmental laws, or to take such action with respect to the containment, clean-up or remediation of hazardous substances, hazardous materials, hazardous wastes, or petroleum-based materials affecting any such Mortgaged Property, then the Master Servicer shall take such action as it deems to be in the best economic interest of the Trust Fund. The cost of any such compliance, containment, clean-up or remediation shall be advanced by the Master Servicer as an expense of the Trust Fund, and the Master Servicer shall be entitled to be reimbursed therefor from the Custodial Account as provided in Section 3.11, any such right of reimbursement being prior to the rights of the Certificateholders to receive any amount in the Custodial Account.

  • Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Title, Management and Disposition of Any REO Mortgage Loan The Master Servicer shall enforce the obligations of the applicable Servicer to administer each REO Mortgage Loan at all times so that each REO Mortgage Loan qualifies as "foreclosure property" under the REMIC Provisions and that it does not earn any "net income from foreclosure property" which is subject to tax under the REMIC Provisions. In the event that a Servicer is unable to dispose of any REO Mortgage Loan within the period mandated by each of the Servicing Agreements, the Master Servicer shall monitor such Servicer to verify that such REO Mortgage Loan is auctioned to the highest bidder within the period so specified. In the event of any such sale of a REO Mortgage Loan, the Custodian shall, at the written request of the Master Servicer and upon being supported with appropriate forms therefor, within five Business Days of the deposit by the Master Servicer of the proceeds of such sale or auction into the Certificate Account, release or cause to be released to the entity identified by the Master Servicer the related Owner Mortgage Loan File, Retained Mortgage Loan File, if applicable, and Servicer Mortgage Loan File and shall execute and deliver such instruments of transfer or assignment, in each case without recourse, as shall be necessary to vest in the auction purchaser title to the REO Mortgage Loan and the Custodian shall have no further responsibility with regard to such Owner Mortgage Loan File, Retained Mortgage Loan File, if applicable, or Servicer Mortgage Loan File. Neither the Trustee, the Master Servicer nor any Servicer, acting on behalf of the Trust Estate, shall provide financing from the Trust Estate to any purchaser of an REO Mortgage Loan.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!