Construction Contractor’s Insurance and Indemnification Sample Clauses

Construction Contractor’s Insurance and Indemnification. If a General Contractor (and its subcontractors) is required to maintain commercial general liability, workers’ compensation and automobile liability insurance coverage, and are required to in any manner extend the benefits of such coverage to the City of Xxxxxxxx, then the City of Lawrence at the specific written request of the PM in each instance, shall request that such General Contractor name the PM as an additional insured. The City of Xxxxxxxx shall not be liable to the PM if such General Contractor fails or refuses to name the PM as an additional insured. If a General Contractor (and its subcontractors) is required to waive subrogation against the City of Xxxxxxxx or to defend and indemnify the City of Xxxxxxxx, then the City of Lawrence shall at the written request of the PM in each instance prior to the advertising for bid of a construction contract endeavor to cause such indemnity to apply to the PM as well if the standard form construction documents do not already do so. Notwithstanding the foregoing, the City of Xxxxxxxx shall not have any liability to the PM for breach of this Article.
AutoNDA by SimpleDocs

Related to Construction Contractor’s Insurance and Indemnification

  • Insurance and Indemnification (a) The Surviving Partnership will at all times after the Effective Time indemnify and hold harmless each person who is at the date of this Agreement, or has been at any time prior to the date of this Agreement, a general partner of the Company (or any general partner, officer or director thereof) or a managing member, general partner, director, officer or employee of any of their respective subsidiaries (“Indemnified Parties”), in each case to the fullest extent permitted by applicable law, with respect to any claim, liability, loss, damage, cost, fees (including reasonable attorneys’ fees) or expense (whenever asserted or claimed) based in whole or in part, or arising in whole or in part out of, any act or omission by that person at or prior to the Effective Time in connection with that person’s duties as a general partner, managing member, director, officer or employee, to the same extent and on the same terms (including with respect to advancement of expenses) provided in the relevant limited partnership agreement, operating agreement or articles of incorporation, or in any indemnification agreements, in effect on the date of this Agreement. The Surviving Partnership will pay all reasonable expenses, including attorney’s fees that may be incurred by any Indemnified Party in enforcing the indemnity and other obligations of the Surviving Partnership under this Section 9.3. (b) Lima and Parent will cause the Surviving Partnership to keep in effect (at no less than their current levels of coverage) for at least six years after the Effective Time the policies or tail liability coverage of (i) general partners’ liability insurance maintained by the General Partners and/or Company and (ii) either directors and officers’ liability insurance, general partner’s liability insurance or managing member liability insurance, as the case may be, maintained by the General Partners, the Company, their respective subsidiaries at the date of this Agreement; provided that (A) Lima and Parent may substitute policies having comparable coverage and amounts and containing similar terms and conditions which are no less advantageous to the persons who are currently covered by those policies and with carriers comparable in terms of credit worthiness to those which have written those policies and (B) neither Lima, Parent nor the Surviving Partnership will be required to pay an annual premium for that insurance in excess of three times the annual premium relating to the year during which this Agreement is executed, but if they are not able to maintain the required insurance for an annual premium for that amount, they will purchase as much coverage as it can obtain for that amount.

  • Insurance and Indemnity Hirers must report any damage to premises, contents (including crockery etc), staff and agents to the Booking Clerk as soon as possible. (a) The Hirer shall be liable for: the cost of repair of any damage (including accidental and malicious damage) done to any part of the premises including the curtilage thereof or the contents of the premises all claims, losses, damages and costs made against or incurred by MVH, their employees, volunteers, agents or invitees in respect of damage or loss of property or injury to persons arising as a result of the use of the premises (including the storage of equipment) by the Hirer, and all claims, losses, damages and costs made against or incurred by MVH, their employees, volunteers, agents or invitees as a result of any nuisance caused to a third party as a result of the use of the premises by the Hirer, and subject to sub-clause (b), the Hirer shall indemnify and keep indemnified accordingly each member of MVH and MVH’s employees, volunteers, agents and invitees against such liabilities. MVH shall take out adequate insurance to insure the liabilities described in sub- clauses (a)(i) above and may, in its discretion and in the case of non-commercial hirers, insure the liabilities described in sub-clauses (a)(ii) and (iii) above. MVH shall claim on its insurance for any liability of the Hirer hereunder but the Hirer shall indemnify and keep indemnified each member of MVH and its employees, volunteers, agents and invitees against (1) any insurance excess incurred and (2) the difference between the amount of the liability and the monies received under the insurance policy. For Commercial Hirers, MVH does not insure the liabilities described in sub-clauses (a)(ii) and (iii) above. A Commercial Hirer shall take out adequate insurance to insure the liabilities described in sub-clauses (a)(ii) and (iii) above and on demand shall produce the policy and current receipt or other evidence of cover to MVH treasurer. Failure to produce such policy and evidence of cover will render the hiring void and enable the MVH to rehire the premises to another Hirer. MVH is insured against any claims arising out of its own negligence.

  • Directors’ and Officers’ Insurance and Indemnification For not less than six (6) years from and after the Effective Date, Aon agrees to indemnify and hold harmless all individuals who at or prior to the Effective Time are past or present directors, officers or employees of WTW or WTW Subsidiaries (collectively, the “Indemnified Parties”) against any costs or expenses (including advancing attorneys’ fees and expenses in advance of the final disposition of any actual or threatened claim, suit, proceeding or investigation to each Indemnified Party to the fullest extent permitted by applicable Law; provided such Indemnified Party agrees in advance to return any such funds to which a court of competent jurisdiction has determined in a final, nonappealable judgment such Indemnified Party is not ultimately entitled), judgments, fines, losses, claims, damages, liabilities and amounts paid in settlement in connection with any actual or threatened claim, action, investigation, suit or proceeding in respect of acts or omissions occurring or alleged to have occurred at or prior to the Effective Time (including acts or omissions occurring in connection with the approval of this Agreement and the consummation of the Acquisition or any of the other Transactions), whether asserted or claimed prior to, at or after the Effective Time, in connection with such persons serving as an officer, director, employee or other fiduciary of WTW or any of the WTW Subsidiaries or of any Person if such service was at the request or for the benefit of WTW or any of the WTW Subsidiaries, to the fullest extent permitted by Law or provided pursuant to WTW Governing Documents or the organizational documents of any WTW Subsidiary or any indemnification agreements, if any, in existence on the date of this Agreement. The Parties agree that all rights to elimination of liability, indemnification and advancement of expenses for acts or omissions occurring or alleged to have occurred at or prior to the Effective Time, whether asserted or claimed prior to, at or after the Effective Time, now existing in favor of the Indemnified Parties as provided in their respective certificate of incorporation or by-laws (or comparable organizational documents) or in any agreement shall survive the Acquisition and shall continue in full force and effect. For six (6) years after the Effective Time, Aon shall cause to be maintained in effect the provisions in (i) WTW Governing Documents and the organizational documents of any WTW Subsidiary and (ii) any other agreements of WTW and WTW Subsidiaries with any Indemnified Party, in each case, regarding elimination of liability, indemnification of officers, directors and employees and advancement of expenses that are in existence on the date of this Agreement, and no such provision shall be amended, modified or repealed in any manner that would adversely affect the rights or protections thereunder of any such Indemnified Party in respect of acts or omissions occurring or alleged to have occurred at or prior to the Effective Time (including acts or omissions occurring in connection with the approval of this Agreement and the consummation of the Acquisition or any of the other Transactions). Aon shall cause for an aggregate period of not less than six (6) years from the Effective Date, the purchase of an insurance and indemnification policy in favor of WTW’s current directors and officers that provides coverage for events occurring prior to the Effective Time (the “D&O Insurance”) that is no less favorable that WTW’s existing policy or, if insurance coverage that is no less favorable is unavailable, the best available coverage; provided, however, that WTW shall not be required to pay an annual premium for the D&O Insurance in excess of three-hundred (300%) of the last annual premium paid prior to the date of this Agreement (it being understood that Aon shall nevertheless be obligated to provide as much coverage as may be obtained for such amount); provided further that WTW may prior to the Effective Time substitute therefor a single premium six-year tail coverage with respect to D&O Insurance with an annual cost not in excess of three-hundred (300%) of the last annual premium paid prior to the date of this Agreement. Notwithstanding anything herein to the contrary, if any Indemnified Party notifies Aon on or prior to the sixth (6th) anniversary of the Effective Time of a matter in respect of which such Person may seek indemnification pursuant to this Section 8.4, the provisions of this Section 8.4 shall continue in effect with respect to such matter until the final disposition of all claims, actions, investigations, suits and proceedings relating thereto. In the event following the Effective Time Aon or any of its respective successors or assigns (i) consolidates with or merges into any other Person and shall not be the continuing or surviving corporation or entity of such consolidation or merger or (ii) transfers all or substantially all of its properties and assets to any Person, then, and in each such case, proper provision shall be made so that the successors and assigns of Aon, as the case may be, shall assume the obligations set forth in this Section 8.4. The rights and obligations under this Section 8.4 shall survive consummation of the Acquisition and shall not be terminated or amended in a manner that is adverse to any Indemnified Party without the written consent of such Indemnified Party. The provisions of this Section 8.4 are intended to be for the benefit of, and will be enforceable by, each Indemnified Party, his or her heirs and his or her legal representatives.

  • Landlord Indemnification With respect to only those Hazardous Substances present on, in or under the Industrial Center as of the date of this Lease (the “Existing Hazardous Substances”), Landlord agrees to indemnify, defend (with counsel reasonably acceptable to Tenant) and hold Tenant harmless from and against any and all claims, judgments, damages, penalties, fines, liabilities, losses, suits, administrative proceedings and costs (including, but not limited to, reasonable attorneys’ and consultant fees and court costs), arising at any time during or after the Term of this Lease, to the extent arising from (1) any of the Existing Hazardous Substances and/or (2) the removal, investigation, monitoring or remediation of any of the Existing Hazardous Substances; provided, however, Landlord shall not indemnify, defend or hold Tenant harmless to the extent (x) Tenant or any of the Tenant Entities contributes to or has contributed to the presence of such Existing Hazardous Substances or Tenant and/or any of the Tenant Entities exacerbates the conditions caused by such Existing Hazardous Substances, or (y) Tenant and/or any of the Tenant Entities allows or permits persons over which Tenant or any of the Tenant Entities has control and/or for which Tenant or any of the Tenant Entities are legally responsible for, to cause such Existing Hazardous Substances to be present in, on, under, through or about any portion of the Premises, the Building or the Industrial Center, or does not take all reasonably appropriate actions to prevent such persons over which Tenant or any of the Tenant Entities has control and/or for which Tenant or any of the Tenant Entities are legally responsible from causing the presence of Existing Hazardous Substances in, on, under, through or about any portion of the Premises, the Building or the Industrial Center. Landlord’s obligations under this Paragraph 6.8 shall survive the Expiration Date or earlier termination of this Lease.

  • Tenant Indemnification Tenant agrees to protect, indemnify, defend and save harmless Landlord, its members, managers, Affiliates, directors, officers, shareholders, agents and employees (the “Landlord Indemnified Parties”) from and against any and all foreseeable or unforeseeable liability, expense, loss, cost, deficiency, fine, penalty or damage (including consequential or punitive damages) of any kind or nature, including reasonable attorneys’ fees, from any third party suits, claims or demands, on account of any matter or thing, action or failure to act arising out of or in connection with Tenant’s occupancy of the Facility in accordance with this Lease, the Premises (arising after the Commencement Date) or the operations of Tenant on any portion of the Premises, including, without limitation, (a) the breach by Tenant of any of its representations, warranties, covenants or other obligations hereunder, (b) any Protest, (c) all Environmental Activities on any portion of the Premises by Tenant, Hazardous Materials Claims caused by Tenant or violations by Tenant of a Hazardous Materials Law with respect to any portion of the Premises (which occurred on or after the Commencement Date), and (d) upon or following the Termination Date, the correction of all deficiencies of a physical matter identified by and any liability assessed or asserted by, any governmental agency or Medicare or Medicaid providers as a result of or arising out or in connection with this Lease or the related change in ownership inspection and audit (including any overpayment to any Medicare, Medicaid or other third party payor). Tenant, at its expense, shall contest, resist and defend any such claim, action or proceeding asserted or instituted against Landlord or any Landlord Indemnified Parties with counsel acceptable to Landlord and shall not, under any circumstances, compromise or otherwise dispose of any suit, action or proceeding without obtaining Landlord’s written consent. Landlord, at its election and sole cost and expense, shall have the right, but not the obligation, to participate in the defense of any claim for which Landlord or any Landlord Indemnified Parties are indemnified hereunder. If Tenant does not act promptly and completely to satisfy its obligations hereunder, Landlord may resist and defend any such claims or causes of action against Landlord or any Landlord Indemnified Party at Tenant’s sole cost.

  • Insurance and Indemnities 15.1 The Service Provider shall maintain the following insurance for the duration of the contract: 15.2 The Service Provider shall hold and maintain the Required Insurances for a minimum of six (6) years following the expiration or earlier termination of the agreement.

  • INSURANCE and INDEMNIFICATION REQUIREMENTS See Exhibit C, attached hereto, for insurance requirements for this Agreement. The COUNTY’S insurance requirements are a material provision to this Agreement.

  • Waiver and Indemnification Tenant waives all claims against Landlord, its Security Holders (defined in Section 17), Landlord’s managing agent(s), their (direct or indirect) owners, and the beneficiaries, trustees, officers, directors, employees and agents of each of the foregoing (including Landlord, the “Landlord Parties”) for (i) any damage to person or property (or resulting from the loss of use thereof), except to the extent such damage is caused by any negligence, willful misconduct or breach of this Lease of or by any Landlord Party, or (ii) any failure to prevent or control any criminal or otherwise wrongful conduct by any third party or to apprehend any third party who has engaged in such conduct. Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any obligation, loss, claim, action, liability, penalty, damage, cost or expense (including reasonable attorneys’ and consultants’ fees and expenses) (each, a “Claim”) that is imposed or asserted by any third party and arises from (a) any cause in, on or about the Premises, or (b) any negligence, willful misconduct or breach of this Lease of or by Tenant, any party claiming by, through or under Tenant, their (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees, agents, contractors, licensees or invitees (each, an “Act of Tenant”), except to the extent such Claim arises from any negligence, willful misconduct or breach of this Lease of or by any Landlord Party. Landlord shall indemnify, defend, protect, and hold Tenant, its (direct or indirect) owners, and their respective beneficiaries, trustees, officers, directors, employees and agents (including Tenant, the “Tenant Parties”) harmless from any Claim that is imposed or asserted by any third party and arises from any negligence, willful misconduct or breach of this Lease of or by any Landlord Party, except to the extent such Claim arises from any negligence, willful misconduct or breach of this Lease of or by any Tenant Party.

  • Insurance Indemnification 7.1 The Independent Contractor shall maintain a policy or policies of liability insurance with coverages (including, but not limited to, professional liability coverage) that is/are sufficient to protect NCISD and the Independent Contractor against any claims, demands, causes of action, or damages arising out of the Independent Contractor’s performance of services under this Agreement. The limits of liability of such policy(ies) shall be in an amount acceptable to NCISD. Such policy(ies) (i) shall be written by companies authorized to issue such insurance policy(ies) in the State of Texas, (ii) shall and must name NCISD as an additional insured, and (iii) shall contain no specific limitations on the coverage afforded additional insureds. 7.2 THE INDEPENDENT CONTRACTOR SHALL INDEMNIFY, HOLD HARMLESS, SAVE, AND DEFEND NCISD AND NCISD’S OFFICERS AND EMPLOYEES FROM AND AGAINST ANY AND ALL CLAIMS, DEMANDS, CAUSES OF ACTION, AND DAMAGES, INCLUDING BUT NOT LIMITED TO REASONABLE ATTORNEYS’ FEES AND EXPENSES, ARISING OUT OF OR IN ANY WAY RELATED TO THIS AGREEMENT, THE PROVISION OF SERVICES BY THE INDEPENDENT CONTRACTOR, OR ANY NEGLIGENT OR INTENTIONAL ACTS OR OMISSIONS OF THE INDEPENDENT CONTRACTOR.

  • Indemnification and Liability Insurance The Subdivider hereby agrees to hold the City of Avon, its officers, directors, agents and employees harmless and to indemnify them against all claims, expenses and liability as a result of loss or injury arising out of the clearing of land or construction of the Subdivision and public improvements. Prior to the commencement of any construction on the Subdivision site, Subdivider agrees to provide the City with proof of One Million ($1,000,000.00) Dollars liability insurance protecting the City from liability arising out of the development of the Subdivision and public improvements. Subdivider shall not allow this insurance to expire earlier than the effective period of any maintenance bond, and shall provide a copy of the insurance policy to remain, at all times, with the Director of Finance of the City.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!