Common use of CONTRACT CONTROVERSIES Clause in Contracts

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this Contract, the Contractor must, within six (6) months after the cause of action occurs, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Program. b. If the Contractor or the Contracting Officer requests mediation and the other party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agency. d. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this Contract in a manner consistent with the determination of the Contracting Officer and the University shall compensate the Contractor pursuant to the terms of this Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this Contract, the Contractor must, within six (6) months after the cause of action occurs, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Program. b. If the Contractor or the Contracting Officer requests mediation and the other party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agency. d. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of ClaimsClaims which retains exclusive jurisdiction. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this Contract in a manner consistent with the determination of the Contracting Officer and the University shall compensate the Contractor pursuant to the terms of this Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this Contractthe Grant Agreement, the Contractor Subgrantee must, within six (6) months after the cause of action occursaccrues, file a written claim with the Contracting Officer Agency’s contracting officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor Subgrantee asserts a controversy exists. If the Contractor Subgrantee fails to file a claim or files an untimely claim, the Contractor Subgrantee is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Dispute Resolution Program. b. If the Contractor Subgrantee or the Contracting Officer contracting officer requests mediation and the other party agrees, the Contracting Officer contracting officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. . If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer contracting officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer contracting officer and the ContractorSubgrantee. The Contracting Officer contracting officer shall send his/her written determination to the ContractorSubgrantee. If the Contracting Officer contracting officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officercontracting officer's determination shall be the final order of the purchasing agency. d. c. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if if, no extension is agreed to by the parties, whichever occurs first, the Contractor Subgrantee may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor Subgrantee shall proceed diligently with the performance of this Contract the Grant Agreement in a manner consistent with the determination of the Contracting Officer and the University shall compensate the Contractor pursuant to the terms of this Contractcontracting officer.

CONTRACT CONTROVERSIES. a. A. In the event of a controversy or claim arising from this Contractthe Agreement or from a Purchase Order, as the case may be, the Contractor UNIVERSITY must, within six (6) months after the cause of action occursaccrues, file a written claim for determination: 1) with the Commonwealth Contracting Officer for claims pertaining to the Agreement; or 2) with the Commonwealth Agency that issued the Purchase Order for claims pertaining to a determination, stating all grounds upon which the Contractor asserts a controversy or claimPurchase Order. The written claim shall state all grounds upon which the Contractor UNIVERSITY asserts a controversy exists. If the Contractor UNIVERSITY fails to file a claim or files an untimely claim, the Contractor UNIVERSITY is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Program. b. If the Contractor or the B. The Commonwealth Contracting Officer requests mediation and or Commonwealth agency, as the other party agreescase may be, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Commonwealth Contracting Officer or Commonwealth agency, as the case may be, and the ContractorUNIVERSITY. The Commonwealth Contracting Officer or Commonwealth agency, as the case may be, shall send his/her written determination to the ContractorUNIVERSITY. If the Commonwealth Contracting Officer or Commonwealth agency, as the case may be, fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Commonwealth Contracting Officer's ’s or Commonwealth agency’s, as the case may be, determination shall be the final order of the purchasing agency. d. C. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if if, no extension is agreed to by the parties, whichever occurs first, the Contractor UNIVERSITY may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor UNIVERSITY shall proceed diligently with the performance of this Contract the Agreement in a manner consistent with the determination of the Commonwealth Contracting Officer or Commonwealth agency, as the case may be, and the University Commonwealth shall compensate the Contractor UNIVERSITY pursuant to the terms of this Contractthe Agreement.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this the Contract, the Contractor must, within six (6) months after the cause of action occursaccrues, file a written claim with the Contracting Officer contracting officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Dispute Resolution Program. b. If the Contractor or the Contracting Officer contracting officer requests mediation and the other party agrees, the Contracting Officer contracting officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. . If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer contracting officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer contracting officer and the Contractor. The Contracting Officer contracting officer shall send his/her written determination to the Contractor. If the Contracting Officer contracting officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officercontracting officer's determination shall be the final order of the purchasing agency. d. c. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if if, no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this the Contract in a manner consistent with the determination of the Contracting Officer contracting officer and the University Commonwealth shall compensate the Contractor pursuant to the terms of this the Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this the Contract, the Contractor must, within six (6) months after the cause of action occursaccrues, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) 60 days thereafter, either party Party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Dispute Resolution Program. b. If the Contractor or the Contracting Officer requests mediation and the other party Party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. . If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer Cfficer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agencyPLCB. d. c. Within fifteen (15) 15 days of the mailing date of the determination denying a claim or within 135 days of filing a claim if if, no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this the Contract in a manner consistent with the determination of the Contracting Officer and the University PLCB shall compensate the Contractor for such continuous performance pursuant to the terms of this the Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this Contract, the Contractor must, within six (6) months after the cause of action occurs, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Program. b. If the Contractor or the Contracting Officer requests mediation and the other party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agency. d. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of ClaimsClaims which retains exclusive jurisdiction. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this Contract in a manner consistent with the determination of the Contracting Officer and the University State System shall compensate the Contractor pursuant to the terms of this Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this Contract, the Contractor must, within six (6) months after the cause of action occurs, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Program. b. If the Contractor or the Contracting Officer requests mediation and the other party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the partiesParties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agency. d. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if no extension is agreed to by the partiesParties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of ClaimsClaims which retains exclusive jurisdiction. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this Contract in a manner consistent with the determination of the Contracting Officer and the University State System shall compensate the Contractor pursuant to the terms of this Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this the Contract, the Contractor ADVISOR must, within six (6) months after the cause of action occursaccrues, file a written claim with the Contracting Officer contracting officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor ADVISOR asserts a controversy exists. If the Contractor ADVISOR fails to file a claim or files an untimely claim, the Contractor ADVISOR is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of PennsylvaniaCommonwealth’s Office of General Counsel Mediation Dispute Resolution Program. b. If the Contractor ADVISOR or the Contracting Officer contracting officer requests mediation and the other party agrees, the Contracting Officer contracting officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. . If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer contracting officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer contracting officer and the ContractorADVISOR. The Contracting Officer contracting officer shall send his/her written determination to the ContractorADVISOR. If the Contracting Officer contracting officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officercontracting officer's determination shall be the final order of the purchasing agency. d. c. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if if, no extension is agreed to by the parties, whichever occurs first, the Contractor ADVISOR may file a statement of claim with the Commonwealth Commonwealth’s Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor ADVISOR shall proceed diligently with the performance of this the Contract in a manner consistent with the determination of the Contracting Officer contracting officer and the University BOARD shall compensate the Contractor ADVISOR pursuant to the terms of this the Contract.

CONTRACT CONTROVERSIES. a. In the event of a controversy or claim arising from this the Contract, the Contractor must, within six (6) months after the cause of action occursaccrues, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) 60 days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Dispute Resolution Program. b. If the Contractor or the Contracting Officer requests mediation and the other party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. . If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely timely-filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agencyPLCB. d. c. Within fifteen (15) 15 days of the mailing date of the determination denying a claim or within 135 days of filing a claim if if, no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this the Contract in a manner consistent with the determination of the Contracting Officer and the University PLCB shall compensate the Contractor for such continuous performance pursuant to the terms of this the Contract.