Stipulated Penalties for Failure to Comply with Certain Obligations As a contractual remedy, the Friendship Entities and OIG hereby agree that failure to comply with certain obligations as set forth in this CIA may lead to the imposition of the following monetary penalties (hereinafter referred to as “Stipulated Penalties”) in accordance with the following provisions. 1. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to establish and implement any of the following obligations as described in Sections III and IV: a. a Compliance Officer; b. a Compliance Committee; c. the Board of Directors compliance obligations and the engagement of a Compliance Expert, the performance of a Compliance Program Review and the preparation of a Compliance Program Review Report, as required by Section III.A.3.; d. the management certification obligations; e. a written Code of Conduct; f. written Policies and Procedures; g. the development and/or implementation of a Training Plan for the training of Covered Persons, Relevant Covered Persons, and Board Members; h. a risk assessment and internal review process as required by Section III.E; i. a Disclosure Program; j. Ineligible Persons screening and removal requirements; k. notification of Government investigations or legal proceedings; l. policies and procedures regarding the repayment of Overpayments; m. the repayment of Overpayments as required by Section III.I and Appendix B; n. reporting of Reportable Events; and o. disclosure of changes to business units or locations. 2. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to engage and use an IRO, as required by Section III.D, Appendix A, or Appendix B. 3. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to submit the Implementation Report or any Annual Reports to OIG in accordance with the requirements of Section V by the deadlines for submission. 4. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to submit any Claims Review or Additional Items Review Report in accordance with the requirements of Section III.D and Appendix B. 5. A Stipulated Penalty of $1,500 for each day the Friendship Entities fail to grant access as required in Section VII. (This Stipulated Penalty shall begin to accrue on the date the Friendship Entities fail to grant access.) 6. A Stipulated Penalty of $50,000 for each false certification submitted by or on behalf of the Friendship Entities as part of their Implementation Report, any Annual Report, additional documentation to a report (as requested by the OIG), or otherwise required by this CIA. 7. A Stipulated Penalty of $1,000 for each day the Friendship Entities fail to comply fully and adequately with any obligation of this CIA. OIG shall provide notice to the Friendship Entities stating the specific grounds for its determination that the Friendship Entities have failed to comply fully and adequately with the CIA obligation(s) at issue and steps the Friendship Entities shall take to comply with the CIA. (This Stipulated Penalty shall begin to accrue 10 days after the date the Friendship Entities receive this notice from OIG of the failure to comply.) A Stipulated Penalty as described in this Subsection shall not be demanded for any violation for which OIG has sought a Stipulated Penalty under Subsections 1- 6 of this Section.
Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .
Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.
Performance of Services in Accordance with Regulatory Requirements; Furnishing of Books and Records In performing the services set forth in this Agreement, the Manager: A. shall conform with the 1940 Act and all rules and regulations thereunder, with all other applicable federal, state and foreign laws and regulations, with any applicable procedures adopted by the Trust’s Board of Trustees, and with the provisions of the Trust’s Registration Statement filed on Form N-1A as supplemented or amended from time to time; B. will make available to the Trust, promptly upon request, any of the Fund’s books and records as are maintained under this Agreement, and will furnish to regulatory authorities having the requisite authority any such books and records and any information or reports in connection with the Manager’s services under this Agreement that may be requested in order to ascertain whether the operations of the Trust are being conducted in a manner consistent with applicable laws and regulations.
Covenant to Comply with Applicable Laws Upon Repurchase of Notes In connection with any repurchase offer, the Company will, if required: (a) comply with the provisions of Rule 13e-4, Rule 14e-1 and any other tender offer rules under the Exchange Act; (b) file a Schedule TO or any other required schedule under the Exchange Act; and (c) otherwise comply with all federal and state securities laws in connection with any offer by the Company to repurchase the Notes; in each case, so as to permit the rights and obligations under this Article 15 to be exercised in the time and in the manner specified in this Article 15.
CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “ (1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “ (1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
Provide Data in Compliance with Applicable Laws LEA shall provide Student Data for the purposes of obtaining the Services in compliance with all applicable federal, state, and local privacy laws, rules, and regulations, all as may be amended from time to time.
Human and Financial Resources to Implement Safeguards Requirements The Borrower shall make available necessary budgetary and human resources to fully implement the EMP and the RP.
Amendment to Comply with Law The Parties acknowledge that state and federal laws and regulations relating to data security and privacy are rapidly evolving and that amendment of this Agreement may be required to provide procedures to ensure compliance with such developments. i. In the event of any change to state or federal laws and regulations relating to data security and privacy affecting this Agreement, the Parties shall take such action as is necessary to implement the changes to the standards and requirements of HIPAA, the HIPAA Rules and other applicable rules relating to the confidentiality, integrity, availability and security of PHI with respect to this Agreement. ii. Business Associate shall provide to Covered Entity written assurance satisfactory to Covered Entity that Business Associate shall adequately safeguard all PHI, and obtain written assurance satisfactory to Covered Entity from Business Associate’s Subcontractors and agents that they shall adequately safeguard all PHI. iii. Upon the request of either Party, the other Party promptly shall negotiate in good faith the terms of an amendment to the Contract embodying written assurances consistent with the standards and requirements of HIPAA, the HIPAA Rules, or other applicable rules. iv. Covered Entity may terminate this Agreement upon 30 days’ prior written notice in the event that: A. Business Associate does not promptly enter into negotiations to amend the Contract and this Agreement when requested by Covered Entity pursuant to this Section; or B. Business Associate does not enter into an amendment to the Contract and this Agreement, which provides assurances regarding the safeguarding of PHI sufficient, in Covered Entity’s sole discretion, to satisfy the standards and requirements of the HIPAA, the HIPAA Rules and applicable law.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
