PRESERVATION, MANAGEMENT AND MAINTENANCE OF MORTGAGED PROPERTY (a) Borrower shall not commit waste or permit impairment or deterioration of the Mortgaged Property.
(b) Borrower shall not abandon the Mortgaged Property.
(c) Borrower shall restore or repair promptly, in a good and workmanlike manner, any damaged part of the Mortgaged Property to the equivalent of its original condition, or such other condition as Lender may approve in writing, whether or not insurance proceeds or condemnation awards are available to cover any costs of such restoration or repair; however, Borrower shall not be obligated to perform such restoration or repair if (i) no Event of Default has occurred and is continuing, and (ii) Lender has elected to apply any available insurance proceeds and/or condemnation awards to the payment of Indebtedness pursuant to Section 19(h)(ii), (iii), (iv) or (v), or pursuant to Section 20.
(d) Borrower shall keep the Mortgaged Property in good repair, including the replacement of Personalty and Fixtures with items of equal or better function and quality.
(e) Borrower shall provide for professional management of the Mortgaged Property by a residential rental property manager satisfactory to Lender at all times under a contract approved by Lender in writing, which contract must be terminable upon not more than 30 days notice without the necessity of establishing cause and without payment of a penalty or termination fee by Borrower or its successors.
(f) Borrower shall give Notice to Lender of and, unless otherwise directed in writing by Lender, shall appear in and defend any action or proceeding purporting to affect the Mortgaged Property, Lender's security or Lender's rights under this Instrument. Borrower shall not (and shall not permit any tenant or other person to) remove, demolish or alter the Mortgaged Property or any part of the Mortgaged Property, including any removal, demolition or alteration occurring in connection with a rehabilitation of all or part of the Mortgaged Property, except (i) in connection with the replacement of tangible Personalty, (ii) if Borrower is a cooperative housing corporation or association, to the extent permitted with respect to individual dwelling units under the form of proprietary lease or occupancy agreement and (iii) repairs and replacements in connection with making an individual unit ready for a new occupant.
(g) Unless otherwise waived by Lender in writing, Borrower must have or must establish and must adhere to the MMP. If the Borrower is required to have an MMP, the Borrower must keep all MMP documentation at the Mortgaged Property or at the management agent's office and available for the Lender or the Loan Servicer to review during any annual assessment or other inspection of the Mortgaged Property that is required by Lender.
(h) If Borrower is a housing cooperative corporation or association, until the Indebtedness is paid in full Borrower shall not reduce the maintenance fees, charges or assessments payable by shareholders or residents under proprietary leases or occupancy agreements below a level which is sufficient to pay all expenses of the Borrower, including, without limitation, all operating and other expenses for the Mortgaged Property and all payments due pursuant to the terms of the Note and any Loan Documents.
CONVEYANCE OF THE SAID APARTMENT The Promoter, on receipt of complete amount of the Price of the [Apartment/Plot] under the Agreement from the Allottee, shall execute a conveyance deed and convey the title of the [Apartment/Plot] together with proportionate indivisible share in the Common Areas within 3 (three) months from the issuance of the occupancy certificate*. However, in case the Allottee fails to deposit the stamp duty, registration charges and all other incidental and legal expenses etc. so demanded within the period mentioned in the demand letter, the Allottee authorizes the Promoter to withhold registration of the conveyance deed in his/her favour till full and final settlement of all dues and stamp duty and registration charges to the Promoter is made by the Allottee. The Allottee shall be solely responsible and liable for compliance of the provisions of Indian Stamp Act, 1899 including any actions taken or deficiencies/ penalties imposed by the competent authority(ies).
Conveyance by Lessor Lessor may assign this Lease to any purchaser of the Leased Property. If Lessor or any successor owner of the Leased Property conveys the Leased Property in accordance with the terms hereof other than as security for a debt, and the grantee or transferee of the Leased Property expressly assumes all obligations of Lessor hereunder arising or accruing from and after the date of such conveyance or transfer, Lessor or such successor owner, as the case may be, shall thereupon be released from all future liabilities and obligations of Lessor under this Lease arising or accruing from and after the date of such conveyance or other transfer as to the Leased Property and all such future liabilities and obligations shall thereupon be binding upon the new owner.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Acceptance of Agreement This Agreement shall not be considered accepted, approved or otherwise effective until the statutorily required approvals and certifications have been given.
Preservation, Maintenance, and Protection of the Property Inspections. Borrower will not destroy, damage, or impair the Property, allow the Property to deteriorate, or commit waste on the Property. Whether or not Borrower is residing in the Property, Borrower must maintain the Property in order to prevent the Property from deteriorating or decreasing in value due to its condition. Unless Lender determines pursuant to Section 5 that repair or restoration is not economically feasible, Borrower will promptly repair the Property if damaged to avoid further deterioration or damage. If insurance or condemnation proceeds are paid to Lender in connection with damage to, or the taking of, the Property, Borrower will be responsible for repairing or restoring the Property only if Xxxxxx has released proceeds for such purposes. Lender may disburse proceeds for the repairs and restoration in a single payment or in a series of progress payments as the work is completed, depending on the size of the repair or restoration, the terms of the repair agreement, and whether Borrower is in Default on the Loan. Lender may make such disbursements directly to Borrower, to the person repairing or restoring the Property, or payable jointly to both. If the insurance or condemnation proceeds are not sufficient to repair or restore the Property, Borrower remains obligated to complete such repair or restoration. Lender may make reasonable entries upon and inspections of the Property. If Lender has reasonable cause, Xxxxxx may inspect the interior of the improvements on the Property. Lender will give Borrower notice at the time of or prior to such an interior inspection specifying such reasonable cause.
Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Acceptance of Leased Premises On or before the Possession Date, Tenant and Landlord shall each execute the letter agreement in the form attached hereto as Exhibit E (the “Letter Agreement”). By its execution of the Letter Agreement or occupancy of the Leased Premises, Tenant shall be deemed to represent and certify that it has examined the Leased Premises and that it thereby accepts the Leased Premises in its condition at the time, except for the list of defects and/or omissions identified in writing prior to the Possession Date (the “Punch-List”) and latent defects, but subject, in all cases, to Landlord’s repair, maintenance and replacement obligations set forth in this Lease and to the warranty related to the Tenant Improvements, as provided in the Work Letter Agreement. After the notice provided in Section 3.03 and prior to the Possession Date, the parties shall meet in the Leased Premises to establish the Punch-List. Landlord shall review the Punch-List items with Tenant and correct all undisputed Punch- List items within a reasonable time, not to exceed thirty (30) days after receipt of the Punch- List; provided that, if any Punch-List items cannot be corrected within such thirty (30) day period despite reasonable diligence by Landlord, then, so long as Landlord commences correction of such Punch-List items within such thirty (30) day period and diligently pursues such correction to completion, no default by Landlord shall be deemed to have occurred. Punch-List items for completion taking longer than six (6) months to complete (and not otherwise the result of Force Majeure, Tenant Delay, or the COVID-19 Condition) shall trigger a day for day prorated Minimum Monthly Rent abatement. The Tenant Improvements shall be subject to a two (2) year warranty, from the Possession Date, with regard to materials, design and workmanship, as provided in more detail in the Work Letter Agreement. Tenant shall reasonably cooperate with Landlord in providing required information as needed for Landlord to pursue vendor warranties on a timely basis, as requested in writing by Landlord. Landlord will pursue any valid warranty claims against its contractor beyond the two (2) year warranty provided that any expenses incurred and/or any recovery obtained shall be treated as either additional Operating Costs or an offset to Operating Costs under Section 5.03(a).
Supply and Maintenance of Equipment It is the responsibility of the Employer to furnish and maintain all equipment, machinery and supplies required by employees in the performance of their duties. Employees shall not suffer any loss in salary in the event that they cannot carry out their normal duties by reason of the Employer failing to properly maintain equipment, machinery or supplies or by reason of power failures or other circumstances not attributable to the employees.
