Operation of the Agreement The Parties recognize that it is impractical in this Agreement to provide for every contingency which may arise during the life of the Agreement, and the Parties hereby agree that it is their intention that this Agreement shall operate fairly as between them, and without detriment to the interest of either of them, and that, if during the term of this Agreement either Party believes that this Agreement is operating unfairly, the Parties will use their best efforts to agree on such action as may be necessary to remove the cause or causes of such unfairness, but failure to agree on any action pursuant to this Clause 8.2 shall not give rise to a dispute subject to arbitration in accordance with Clause 9 hereof.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
Implementation of the Agreement Regulations of this Agreement relating to investments who investors of one Contracting Party realized before or after the entry into force of this Agreement, with what shall apply from the moment of its entry into force, provided that such investments conducted in accordance with the laws of that Party Contracting.
Cooperation of the Parties The Seller undertakes to notify the Buyer of any obstacles on his part, which may negatively influence proper and timely delivery of the Equipment.
Execution of the Agreement The Company, the party executing this Agreement on behalf of the Company, and the Consultant, have the requisite corporate power and authority to enter into and carry out the terms and conditions of this Agreement, as well as all transactions contemplated hereunder. All corporate proceedings have been taken and all corporate authorizations and approvals have been secured which are necessary to authorize the execution, delivery and performance by the Company and the Consultant of this Agreement. This Agreement has been duly and validly executed and delivered by the Company and the Consultant and constitutes a valid and binding obligation, enforceable in accordance with the respective terms herein. Upon delivery of this Agreement, this Agreement, and the other agreements and exhibits referred to herein, will constitute the valid and binding obligations of Company, and will be enforceable in accordance with their respective terms. Delivery may take place via facsimile transmission.
POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Organization of the Buyer The Buyer is a corporation duly organized, validly existing, and in good standing under the laws of the jurisdiction of its incorporation.
Cooperation of Parties The Parties to this Agreement agree to cooperate in good faith to prepare and execute all documents, to seek Court approval, defend Court approval, and to do all things reasonably necessary to complete and effectuate the Settlement described in this Agreement.
Application of the Agreement (1) This Agreement shall apply to investments made in the territory of either Contracting Party in accordance with its legislation by investors of the other Contracting Party prior as well as after the entry into force of this Agreement. (2) This Agreement shall not apply to claims which have been settled or procedures which have been initiated prior to its entry into force.
