Required Submittals Complete shop drawings and manufacturer’s catalog data shall be submitted to the State and approved by the State prior to start of any construction work. Power and lighting panel configuration shall be complete with schedule of branch panels, separate disconnects, and circuit breakers, based on calculated and estimated motor, resistive and lighting loads. All circuits shall be labeled at the panel and at the outlet/power pole for future reference. Location of all electrical receptacles and telephone outlets (including power drops for the systems furnishings) shall be designated on a block floor plan showing the systems furnishings layout provided by the State. Said block floor plan shall be furnished by the State to the Owner/Lessor no later than 4 weeks after approved construction plans are received by the State.
Review of Submittals A/E and ODR review is only for conformance with the design concept and the information provided in the Contract Documents. Responses to submittals will be in writing. The approval of a separate item does not indicate approval of an assembly in which the item functions. The approval of a submittal does not relieve the Contractor of responsibility for any deviation from the requirements of the Contract unless the Contractor informs the A/E and ODR of such deviation in a clear, conspicuous, and written manner on the submittal transmittal and at the time of submission, and obtains the A/E’s and Owner’s written specific approval of the particular deviation.
Sentencing Guidelines Calculations 8. Defendant understands that in imposing sentence the Court will be guided by the United States Sentencing Guidelines. Defendant understands that the Sentencing Guidelines are advisory, not mandatory, but that the Court must consider the Guidelines in determining a reasonable sentence.
Additional RO Review Criteria (1) In addition to the requirements in Subparagraph 34A, the RO must:
Contractor’s Submittals The Contract shall submit with reasonable promptness consistent with the Work Project Schedule and in orderly sequence all Shop Drawings, Samples, or other information required by the Contract Documents, or subsequently required by Change Order. Prior to submitting, the Contractor shall review each submittal for compliance with the Contract Documents and certify its approval by an approval stamp affixed to each copy. Submittal data presented without the Contractor’s certification will be returned without review or comment, and any delay resulting from such certification is the Contractor's responsibility.
Invoice Submittal DEO shall reimburse Subrecipient in accordance with Section 6, above. In accordance with the Funding Requirements of s. 215.971(1), F.S. and Section 21 of this Agreement, Subrecipient and its subcontractors may only expend funding under this Agreement for allowable costs resulting from obligations incurred during this Agreement. To be eligible for reimbursement, costs must be in compliance with laws, rules and regulations applicable to expenditures of State funds, including, but not limited to, the Reference Guide for State Expenditures (xxxxx://xxx.xxxxxxxxxxxx.xxx/Division/AA/Manuals/documents/ReferenceGuideforStateExpenditures.pdf).
Submittals Submittals required by the Contract Documents shall be prepared specifically for the Work by the Contractor to illustrate some portion of the Work. Submittals are not Contract Documents.
Benchmarking Report For the purposes of this Framework Schedule 12 “
AUDIT REPORT SUBMISSION Audit reports must be submitted no later than 150 days following cancellation, termination or expiration of this Agreement.
REPORT SUBMISSION 1. Copies of reporting packages for audits conducted in accordance with 2 CFR Part 200, Subpart F-Audit Requirements, and required by PART I of this form shall be submitted, when required by 2 CFR 200.512, by or on behalf of the recipient directly to the Federal Audit Clearinghouse (FAC) as provided in 2 CFR 200.36 and 200.512
