Requirements for Protection In compliance with NPCC requirements and Good Utility Practice, Developer shall provide, install, own, and maintain relays, circuit breakers and all other devices necessary to remove any fault contribution of the Large Generating Facility to any short circuit occurring on the New York State Transmission System not otherwise isolated by Connecting Transmission Owner’s equipment, such that the removal of the fault contribution shall be coordinated with the protective requirements of the New York State Transmission System. Such protective equipment shall include, without limitation, a disconnecting device or switch with load- interrupting capability located between the Large Generating Facility and the New York State Transmission System at a site selected upon mutual agreement (not to be unreasonably withheld, conditioned or delayed) of the Developer and Connecting Transmission Owner. Developer shall be responsible for protection of the Large Generating Facility and Developer’s other equipment from such conditions as negative sequence currents, over- or under-frequency, sudden load rejection, over- or under-voltage, and generator loss-of-field. Developer shall be solely responsible to disconnect the Large Generating Facility and Developer’s other equipment if conditions on the New York State Transmission System could adversely affect the Large Generating Facility.
Protection of Rights Licensee shall not copy, translate, disassemble, decompile, nor reverse engineer the Software or other SAP Materials. Licensee shall not create or attempt to create the source code from the object code of the Software or other SAP Materials. Licensee is permitted to back up data in accordance with good information technology practice and for this purpose to create the necessary backup copies of the Software. Backup copies on transportable discs or other data media must be marked as backup copies and bear the same copyright and authorship notice as the original discs or other data media, unless technically infeasible. Licensee must not change or remove SAP’s copyright and authorship notices.
Procedure for Surrender of Rights Rights may be surrendered to the Right Agent, together with a written request for exchange or transfer, and thereupon the Right Agent shall issue in exchange therefor one or more new Rights as requested by the registered holder of the Rights so surrendered, representing an equal aggregate number of Rights; provided, however, that in the event that a Right surrendered for transfer bears a restrictive legend, the Right Agent shall not cancel such Right and issue new Rights in exchange therefor until the Right Agent has received an opinion of counsel for the Company stating that such transfer may be made and indicating whether the new Rights must also bear a restrictive legend.
Procedure for Claims (1) In the event the Indemnitee is named as a party in any action, claim, suit, proceeding or investigation upon which the Indemnitee intends to base a claim for indemnification hereunder, the Indemnitee shall give the Indemnitor prompt written notice of such action, claim, suit, proceeding or investigation (provided, however, that failure of the Indemnitee to provide such notice shall not relieve the Indemnitor of any liability to the Indemnitee the Indemnitor may have under this Agreement except to the extent that the Indemnitor is materially prejudiced by such failure).
(2) The Indemnitor shall participate in and, assume the defence of any such action, including for certainty any derivative action, claim, suit, proceeding or investigation all at the Indemnitor's expense provided, however, that counsel retained by the Indemnitor shall be satisfactory to the Indemnitee in the exercise of his reasonable judgement. Notwithstanding the Indemnitor's assumption of the defense of such action, claim, suit, proceeding or investigation, the Indemnitee shall have the right to employ separate counsel and to participate in, but not control, the defense of such action, claim, suit, proceeding or investigation, and the Indemnitor shall bear the reasonable fees, costs and expenses of such separate counsel as such fees, costs and expenses are incurred (provided that with respect to any single action, claim, suit, proceeding or investigation, the Indemnitor shall not be required to bear the fees, costs and expenses of more than one such counsel in any single jurisdiction) if (a) the use of counsel chosen by the Indemnitor to represent the Indemnitee would present such counsel with a conflict of interest; (b) the defendants, respondents or other parties in any such action, claim, suit, proceeding or investigation include both the Indemnitee on the one hand and the Indemnitor on the other hand, and the Indemnitee has reasonably concluded that representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them (in which case the Indemnitor shall not have the right to direct the defense of such action, claim, suit, proceeding or investigation on behalf of the Indemnitee); (c) the Indemnitor shall not have employed counsel satisfactory to the Indemnitee in the exercise of the Indemnitee's reasonable judgment to represent him, within a reasonable time after notice of the institution of such action, proceeding or investigation; or (d) the Indemnitor authorizes the Indemnitee to employ separate counsel at the Indemnitor's expense.
(3) The Indemnitee shall cooperate with the Indemnitor in the Indemnitor's defense by providing such information and other assistance which the Indemnitor may reasonably request in connection with such defense.
(4) The Indemnitor shall not, without the Indemnitee's prior written consent, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit or proceeding in respect of which indemnification may be sought hereunder (whether or not the Indemnitee is a party thereto) unless such settlement, compromise, consent or termination includes a release of the Indemnitee from any liabilities arising out of such action, claim, suit or proceeding. The Indemnitee shall not, without the Indemnitor's prior written consent, admit liability, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit, investigation or proceeding referred to in the preceding paragraph and the Indemnitee shall not disclose the existence of this Agreement unless required by law, subpoena, court order or upon the advice of counsel.
Application of Takeover Protections; Rights Agreements The Company and the Board of Directors have taken all necessary action, if any, in order to render inapplicable any control share acquisition, business combination, poison pill (including any distribution under a rights agreement) or other similar anti-takeover provision under the Company’s charter documents or the laws of its state of incorporation that is or could reasonably be expected to become applicable to any of the Purchasers as a result of the Purchasers and the Company fulfilling their obligations or exercising their rights under the Transaction Documents, including, without limitation, the Company’s issuance of the Securities and the Purchasers’ ownership of the Securities.
Modification of Rights The rights of the Optionee are subject to modification and termination in certain events as provided in this Option Agreement and the Plan.
Application of Takeover Protections; Rights Agreement The Company and its board of directors have taken all necessary action, if any, in order to render inapplicable any control share acquisition, interested stockholder, business combination, poison pill (including, without limitation, any distribution under a rights agreement), stockholder rights plan or other similar anti-takeover provision under the Certificate of Incorporation, Bylaws or other organizational documents or the laws of the jurisdiction of its incorporation or otherwise which is or could become applicable to any Buyer as a result of the transactions contemplated by this Agreement, including, without limitation, the Company’s issuance of the Securities and any Buyer’s ownership of the Securities. The Company and its board of directors have taken all necessary action, if any, in order to render inapplicable any stockholder rights plan or similar arrangement relating to accumulations of beneficial ownership of shares of Common Stock or a change in control of the Company or any of its Subsidiaries.
Reservation of Rights NYISO and Connecting Transmission Owner shall have the right to make unilateral filings with FERC to modify this Agreement with respect to any rates, terms and conditions, charges, classifications of service, rule or regulation under section 205 or any other applicable provision of the Federal Power Act and FERC’s rules and regulations thereunder, and Developer shall have the right to make a unilateral filing with FERC to modify this Agreement pursuant to section 206 or any other applicable provision of the Federal Power Act and FERC’s rules and regulations thereunder; provided that each Party shall have the right to protest any such filing by another Party and to participate fully in any proceeding before FERC in which such modifications may be considered. Nothing in this Agreement shall limit the rights of the Parties or of FERC under sections 205 or 206 of the Federal Power Act and FERC’s rules and regulations thereunder, except to the extent that the Parties otherwise mutually agree as provided herein.
Preservation of Rights No delay or omission of the Lenders or the Administrative Agent to exercise any right under the Loan Documents shall impair such right or be construed to be a waiver of any Default or an acquiescence therein, and the making of a Loan notwithstanding the existence of a Default or the inability of the Borrower to satisfy the conditions precedent to such Loan shall not constitute any waiver or acquiescence. Any single or partial exercise of any such right shall not preclude other or further exercise thereof or the exercise of any other right, and no waiver, amendment or other variation of the terms, conditions or provisions of the Loan Documents whatsoever shall be valid unless in writing signed by the Lenders required pursuant to Section 8.2, and then only to the extent in such writing specifically set forth. All remedies contained in the Loan Documents or by law afforded shall be cumulative and all shall be available to the Administrative Agent and the Lenders until the Obligations have been paid in full.
Freedom of Information and Protection of Privacy Act Any information provided on this contract may be subject to release under the Freedom of Information and Protection of Privacy Act. The Contractor may be consulted prior to release of any information.
