Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Limitation of Administrative Costs Worksheet The worksheet is intended for use during the budgeting process to estimate the district's percent increase of FY2021 budgeted expenditures over FY2020 actual expenditures. Budget information is copied to this page. Insert the prior year estimated actual expenditures to compute the estimated percentage increase (decrease).
Payment of Additional Costs If termination of this contract is due to the failure of the Engineer to fulfill its contract obligations, the State may take over the project and prosecute the work to completion, and the Engineer shall be liable to the State for any additional cost to the State.
Emergency Rate Redetermination Forest Service shall redetermine rates if, upon Purchaser's application, Forest Service determies that, because of changes in the timber market since the award date or the last rate redetermination under this provision, the Producer Price Index identified in A20 has declined by 25 percent. Rates shall be redetermined under B3.3 and shall be considered established under B3.1 for timber Scaled subsequent to Purchaser's application. This Subsection shall not apply during Contract Term Extension.
Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
Allocation of Subordinate Reduction Amount to the Reference Tranches On each Payment Date prior to the Termination Date, after allocation of the Senior Reduction Amount and the Tranche Write-down Amount or Tranche Write-up Amount, if any, for such Payment Date as described above, the Subordinate Reduction Amount will be allocated to reduce the Class Notional Amount of each Class of Reference Tranche in the following order of priority, in each case until its Class Notional Amount is reduced to zero:
Additional Facilities If the CAISO determines that it requires Operational Control over additional transmission lines and associated facilities not then constituting part of the CAISO Controlled Grid in order to fulfill its responsibilities in relation to the CAISO Controlled Grid then the CAISO shall apply to FERC pursuant to Section 203 of the Federal Power Act, and shall make all other regulatory filings necessary to obtain approval for such change of control and shall serve a copy of all such applications on the affected Participating TO and the owner of such lines and facilities (if other than the Participating TO). In the event that a Party invokes the dispute resolution provisions identified in Section 15 with respect to the transfer of Operational Control over a facility, such facility shall not be transferred while the dispute resolution process is pending except pursuant to Section 4.5.2.
NOTICE OF SUPPLEMENTAL ALLOCATION OF FUNDS By the signature below, the City Controller certifies that, upon the request of the Director, the supplemental sum set out below has been allocated for the purposes of the Agreement out of funds appropriated for this purpose by the City Council of the City of Houston. This Supplemental Allocation has been charged to such appropriation. $
Designated on Sale Area Map Purchaser shall keep roads and trails needed for fire protection or other purposes and designated on Sale Area Map reasonably free of equipment and products, slash, and debris resulting from Purchaser’s Operations. Purchaser shall make timely restoration of any such im- provements damaged by Purchaser’s Operations and, when necessary because of such operations, shall move such improvements, as specified in C6.22. B6.221 Protection of Improvements Not Owned by Forest Service. Forest Service will notify all utility companies, or other parties affected, and make ar- rangements for all necessary adjustments of the public utility fixtures, pipelines, and other appurtenances likely to be affected by Purchaser’s Operations. When Purchaser’s Operations are adjacent to proper- ties of railway, telephone, or power companies, or other property, work shall not begin until Purchaser has identi- fied actions necessary to prevent damage. Purchaser shall cooperate with the owners of any un- derground or overhead utility lines in their removal and/or rearrangement operations in order that these operations may progress in a reasonable manner, utility duplication or rearrangement work may be reduced to a minimum, and services shall not be unnecessarily interrupted. In the event of interruption to utility services because of accidental breakage or as a result of lines being ex- posed or unsupported, Purchaser shall promptly notify the proper authority and shall cooperate with that authority in the restoration of service until the service is restored. When materials are to be hauled across the tracks of any railway, Forest Service will make arrangements with the railroad for the use of any existing crossing or for any new crossing required. Purchaser shall make arrange- ments for use of alternate crossings. All construction work to be performed by Purchaser on the railroad right-of-way shall not damage railroad company’s property. B6.222 Protection of Property. In construc- tion and reconstruction of Specified Roads, Purchaser shall not unnecessarily remove, deface, injure, or destroy trees, shrubs, or other natural features, unless specifically authorized. To the extent practicable, Purchaser shall confine operations to within the clearing limit or other ar- eas designated in the contract and prevent the depositing of rocks, excavated materials, stumps, or other debris outside these limits. Material that falls outside these limits shall be re- trieved, disposed of, or incorporated in the work to the ex- tent practicable and necessary to protect adjacent re- source values, unless otherwise agreed. B6.23 Protection of Land Survey Monuments. Forest Service shall appropriately designate on the ground all known survey monuments, section corners, and other corner accessories. Forest Service shall post identifying signs on two sides of each known bearing tree. Forest Service shall arrange protective or per- petuative action that does not cause unnecessary delay to Purchaser in authorized clearings, such as Clearcutting Units and road construction, and in other instances where damage to monuments, section corners, and other corner accessories is unavoidable. Purchaser shall protect all known survey monuments, witness corners, reference monuments, and bearing trees against avoidable destruction, obliteration, or damage during Purchaser’s Operations. If any known monuments, corners, or accessories are destroyed, obliterated, or damaged by Purchaser’s Operations, Purchaser shall hire the appropriate county surveyor or a registered land sur- veyor to reestablish or restore at the same location the monuments, corners, or accessories. Such surveyors shall use procedures in accordance with the Bureau of Land Management “Manual of Instructions for the Survey of the Public Lands of the United States” for General Land Office surveys and in accordance with State law for others. Purchaser shall record such survey in appropriate county records.
Credit for Project Work In order to compensate PURCHASER for project work that PURCHASER agrees to complete under the section titled, “Project Work,” of this contract, STATE agrees to credit PURCHASER’s timber account in the sum of $46,657 upon completion of and STATE’s acceptance of all work, unless otherwise approved in writing by STATE. PURCHASER may request partial credit for project work when PURCHASER has completed and STATE has accepted project work, in accordance with the following credit schedule: Partial credit amount of $24,999 (Project No. 1 completion) Partial credit amount of $ 545 (Project No. 2 completion) Partial credit amount of $ 2,721 (Project No. 3 completion) Partial credit amount of $ 1,753 (Project No. 4 completion) Partial credit amount of $16,639 (Project No. 5 completion)
