Delivery of Possession Landlord shall be deemed to have delivered possession of the Premises to Tenant on the Commencement Date, as it may be adjusted pursuant to the Workletter. Landlord shall construct or install in the Premises the improvements to be constructed or installed by Landlord according to the Workletter. If no Workletter is attached to this Lease, it shall be deemed that Landlord delivered to Tenant possession of the Premises "as is" in its present condition on the Commencement Date. Tenant acknowledges that neither Landlord nor its agents or employees have made any representations or warranties as to the suitability or fitness of the Premises for the conduct of Tenant's business or for any other purpose, nor has Landlord or its agents or employees agreed to undertake any alterations or construct any Tenant improvements to the Premises except as expressly provided in this Lease and the Workletter. If for any reason Landlord cannot deliver possession of the Premises to Tenant on the Commencement Date, this Lease will not be void or voidable, Landlord will not be liable to Tenant for any resulting loss or damage and the Term of this Lease shall not be extended by a delayed delivery of possession. The preceding sentence notwithstanding, if Landlord fails to deliver possession to Tenant within sixty (60) days after the Commencement Date for any reason other than a Delay Caused by Tenant, as defined in the Workletter, Tenant, as its sole remedy, shall have the right to terminate this Lease and receive a refund of all prepaid Rent and Security Deposits provided Tenant gives written notice of termination to Landlord within three (3) days after that date. Tenant will execute the Commencement Date Certificate attached to this Lease as Exhibit E, appropriately completed, within fifteen (15) days of Landlord's request.
NON-DELIVERY OF POSSESSION In the event Landlord cannot deliver possession of the Premises to Tenant upon the commencement of the Lease term, through no fault of Landlord or its agents, then Landlord or its agents shall have no liability, but the rental herein provided shall xxxxx until possession is given. Landlord or its agents shall have thirty (30) days in which to give possession, and if possession is tendered within such time, Tenant agrees to accept the demised Premises and pay the rental herein provided from that date. In the event possession cannot be delivered within such time, through no fault of Landlord or its agents, then this Agreement and all rights hereunder shall terminate.
Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.
Surrender of Possession Upon the expiration or upon the sooner termination of this Lease, Tenant shall remove all of Tenant’s signs from the exterior of the Building and shall remove all of Tenant’s inventory, equipment, trade fixtures, furniture, supplies, wall decorations and other personal property (collectively, “Tenant’s FF&E”) from within the Leased Premises, including the Building and the Outside Areas, and shall vacate and surrender the Leased Premises, and all portions thereof, to Landlord broom clean and in good condition, reasonable wear and tear excepted. Tenant shall repair all damage to the Leased Premises, and all portions thereof, caused by Tenant’s removal of Tenant’s property. Tenant shall patch and refinish, to Landlord’s reasonable satisfaction, all penetrations made by Tenant or its employees to the floor, walls or ceiling of the Leased Premises, whether such penetrations were made with Landlord’s approval or not. Tenant shall repair or replace all stained or damaged ceiling tiles, wall coverings and floor coverings to the reasonable satisfaction of Landlord. Tenant shall repair all damage caused by Tenant to the exterior surface of the Building and the paved surfaces of the Outside Areas and, where necessary, replace or resurface same. Additionally, to the extent that Landlord shall have notified Tenant in writing at the time Landlord approved any improvements requiring Landlord approval that it desired to have such improvements removed at the expiration or sooner termination of the Lease (“Required Removables”), Tenant shall, upon the expiration or sooner termination of the Lease, remove the Required Removables and repair all damage caused by such removal. If Tenant fails to comply with the terms of this Pxxxxxxxx 0.0, Xxxxxxxx may perform Tenant’s obligations at Tenant’s expense, and Tenant shall be liable to Landlord for all reasonable costs incurred by Landlord in performing such obligations for Tenant (including, without limitation, reasonable costs of Landlord’s oversight of removal, repair and replacement work). Tenant shall pay to Landlord the amount of all costs so incurred within fifteen (15) days of Landlord’s delivery to Tenant of an invoice together with reasonable supporting information. Tenant shall indemnify Landlord against loss or liability resulting from delay by Tenant in surrendering the Leased Premises, including, without limitation, any claims made by any succeeding tenant or any losses to Landlord with respect to lost opportunities to lease to succeeding tenants.
Delivery of Agreement The Agency covenants to use reasonable efforts to deliver to each Taxing Entity a copy of this Agreement within fifteen (15) days after its execution.
Delivery of Services Axon personnel will work Monday through Friday, 8:30 a.m. to 5:30 p.m., except holidays. Axon will perform all on-site tasks over a consecutive timeframe. Axon will not charge Agency travel time by Axon personnel to Agency premises as work hours.
Delivery of Funds No later than one (1) business day after the execution of this Agreement by the Investor and the Company, the Investor shall remit by wire transfer the amount of funds equal to the aggregate purchase price for the Units being purchased by the Investor to the following account designated by the Company and the Placement Agent pursuant to the terms of that certain Escrow Agreement (the “Escrow Agreement”) dated as of the date hereof, by and among the Company, the Placement Agent and JPMorgan Chase Bank, N.A. (the “Escrow Agent”): JPMorgan Chase Bank, N.A. ABA # 000000000 Account Name: QuickLogic Corporation Account Number: 806033411, Quick Logic Escrow Account Attention: Xxxxxx Xxxxx Tel: (000) 000-0000 Such funds shall be held in escrow until the Closing and delivered by the Escrow Agent on behalf of the Investors to the Company upon the satisfaction, in the sole judgment of the Placement Agent, of the conditions set forth in Section 3.2(b) hereof. The Placement Agent shall have no rights in or to any of the escrowed funds, unless the Placement Agent and the Escrow Agent are notified in writing by the Company in connection with the Closing that a portion of the escrowed funds shall be applied to the Placement Fee. The Company agrees to indemnify and hold the Escrow Agent harmless from and against any and all losses, costs, damages, expenses and claims (including, without limitation, court costs and reasonable attorneys fees) (“Losses”) arising under this Section 3.3 or otherwise with respect to the funds held in escrow pursuant hereto or arising under the Escrow Agreement, unless it is finally, judicially determined that such Losses resulted directly from the willful misconduct or gross negligence of the Escrow Agent. Anything in this Agreement to the contrary notwithstanding, in no event shall the Escrow Agent be liable for any special, indirect or consequential loss or damage of any kind whatsoever (including but not limited to lost profits), even if the Escrow Agent has been advised of the likelihood of such loss or damage and regardless of the form of action.
Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.
DELIVERY OF PUT NOTICES (I) Subject to the terms and conditions of the Equity Line Transaction Documents, and from time to time during the Open Period, the Company may, in its sole discretion, deliver a Put Notice to the Investor which states the dollar amount (designated in U.S. Dollars) (the "Put Amount"), which the Company intends to sell to the Investor on a Closing Date (the "Put"). The Put Notice shall be in the form attached hereto as Exhibit C and incorporated herein by reference. The amount that the Company shall be entitled to Put to the Investor (the "Put Amount") shall be equal to, at the Company's election, either: (A) Two Hundred percent (200%) of the average daily volume (U.S. market only) of the Common Stock for the Ten (10) Trading Days prior to the applicable Put Notice Date, multiplied by the average of the three (3) daily closing bid prices immediately preceding the Put Date, or (B) two hundred fifty thousand dollars ($250,000). During the Open Period, the Company shall not be entitled to submit a Put Notice until after the previous Closing has been completed. The Purchase Price for the Common Stock identified in the Put Notice shall be equal to ninety-three percent (93%) of the lowest Volume Weighted Average Price (VWAP) of the Common Stock during the Pricing Period.
Delivery of Equipment (a) We will try to deliver Equipment to you on the delivery date (Delivery Date) and at the address (Site) indicated on your Application during normal business hours in that area. (b) Variations at your request to Delivery Date or Site: (i) are at our discretion; and (ii) may be subject to conditions, including extra Charges.
