Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Expenses Indemnity Damage Waiver (a) The Borrower shall pay (i) all reasonable out-of-pocket expenses incurred by the Administrative Agent and its Affiliates, including the reasonable fees, charges and disbursements of counsel for the Administrative Agent, in connection with the syndication and distribution (including, without limitation, via the internet or through a service such as Intralinks) of the credit facilities provided for herein, the preparation and administration of this Agreement and the other Loan Documents or any amendments, modifications or waivers of the provisions hereof or thereof (whether or not the transactions contemplated hereby or thereby shall be consummated), (ii) all reasonable out-of-pocket expenses incurred by the Issuing Bank in connection with the issuance, amendment, renewal or extension of any Letter of Credit or any demand for payment thereunder and (iii) all out-of-pocket expenses incurred by the Administrative Agent, the Issuing Bank or any Lender, including the fees, charges and disbursements of any counsel for the Administrative Agent, the Issuing Bank or any Lender, in connection with the enforcement or protection of its rights in connection with this Agreement and any other Loan Document, including its rights under this Section, or in connection with the Loans made or Letters of Credit issued hereunder, including all such out-of-pocket expenses incurred during any workout, restructuring or negotiations in respect of such Loans or Letters of Credit.
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Remedy Damages The Contractor shall promptly remedy damages and loss to property at the Site caused by the Contractor, by any Subcontractor, by anyone directly or indirectly employed by the Contractor or any such Subcontractor, or by anyone for whose acts the Contractor or any such Subcontractor may be liable. Should the Contractor cause damage to any Separate Contractor‘s work, the Contractor agrees, upon due notice, to settle with the Separate Contractor.
Payment in the Event Losses Fail to Reach Expected Level On the date that is 45 days following the last day (such day, the “True-Up Measurement Date”) of the Final Shared Loss Month, or upon the final disposition of all Shared Loss Assets under this Single Family Shared-Loss Agreement at any time after the termination of the Commercial Shared-Loss Agreement, the Assuming Institution shall pay to the Receiver fifty percent (50%) of the excess, if any, of (i) twenty percent (20%) of the Intrinsic Loss Estimate less (ii) the sum of (A) twenty-five percent (25%) of the asset premium (discount) plus (B) twenty-five percent (25%) of the Cumulative Shared-Loss Payments plus (C) the Cumulative Servicing Amount. The Assuming Institution shall deliver to the Receiver not later than 30 days following the True-Up Measurement Date, a schedule, signed by an officer of the Assuming Institution, setting forth in reasonable detail the calculation of the Cumulative Shared-Loss Payments and the Cumulative Servicing Amount.
Compensation for Damages and Losses Investors of either Contracting Party whose investments suffer losses in the territory of the other Contracting Party owing to war or other armed conflict, revolution, a state of national emergency or revolt, shall be accorded treatment by such other Contracting Party not less favourable than that which the latter Contracting Party accords to its own investors or to investors of any third State as regards restitution, indemnification, compensation or other valuable consideration.
Rate Redetermination after Catastro- phic Damage In event of Catastrophic Damage and ad- justment, if any, of Included Timber, Contracting Officer shall make an appraisal to determine for each species the catastrophe-caused difference between the appraised unit value of Included Timber remaining immediately prior to the catastrophe and the appraised unit value of existing and potential Included Timber immediately after the ca- tastrophe. Included Timber is any that would not be elimi- nated under B8.32. Potential Included Timber is any that would be added under B8.32. Tentative Rates and Flat Rates in effect at the time of catastrophe shall be adjusted by said differences to be- come the redetermined rates for the purpose of a contract modification under B8.32. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to new Base Rate limitations of 25 cents per hun- dred cubic feet or equivalent. However, existing Base In- dices shall not be changed under this Subsection. Upon agreement under B8.32, redetermined rates and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to Catastrophic Damage. At time of such appraisal, Specified Road construc- tion cost shall include the estimated cost of any construc- tion work listed in the Schedule of Items performed and abandoned.
Compensation for Damage or Loss (1) When investments made by investors of either Contracting Party suffer damage or loss owing to war or other armed conflict, a state of national emergency, revolt, civil disturbances, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party, treatment, as regards restitution, indemnification, compensation or other settlement, not less favourable than that the latter Contracting Party accords to its own investors or investors of any third state, whichever is the most favourable.
Property Damages The User’s guests are required to respect all University property. • Guests may not remodel, alter, tamper with or move furniture, electrical or mechanical fixtures, or other University property. • The User agrees to refrain from the use of adhesives, nails, or items that may damage the premises. No decorations or temporary fixtures may be affixed to plants, trees, woodwork, buildings or any architectural feature with nails, tacks, staples, or any application that will cause irreversible damage to landscaping or structures. Duct tape and white masking tape are not permitted on any building, hardscape or lighting fixtures. Neither lights nor decorations may be placed on trees or plants. • Any outdoor signage must be reviewed and approved by University prior to installation. Stakes may not be placed deeper than 5 inches into the grass in order to protect sprinklers and other underground pipes. • Charges will be assessed on the Final Invoice for damages to buildings, furniture, lawns and/or equipment. The University will, to the best of its ability, try to document the names of guests when damages occur but cannot always obtain such information.
Cyber incident damage assessment activities If DoD elects to conduct a damage assessment, the Contracting Officer will request that the Contractor provide all of the damage assessment information gathered in accordance with paragraph (e) of this clause.
