Damages Stipulation Sample Clauses

Damages Stipulation. Each Party expressly agrees and stipulates that the terms, conditions, and payment obligations set forth in Sections 20 and 21 are a reasonable methodology to approximate or determine harm or loss, each Party acknowledges the difficulty of determining actual damages or loss, and each Party hereby waives the right to contest such damages and payments as unenforceable, as an unreasonable penalty, or otherwise for any reason. The Parties further acknowledge and agree that damages and payments determined under Sections 20 and 21 are direct damages, will be deemed to be a direct loss, and will not be excluded from liability or recovery under the Limitations of Liabilities provisions of this Section 22.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Damages Stipulation. Each Party stipulates that the payment obligations set forth in this Article 3.8 for the damages incurred are a reasonable approximation of the anticipated harm or loss and acknowledges the difficulty of estimation or calculation of actual damages, and each Party hereby waives the right to contest such payments as unenforceable, an unreasonable penalty or otherwise.
Sample 1Sample 2See All (9)
Damages Stipulation. Each Party stipulates that the payment obligations set forth in this Agreement, including in Sections 9, 11.2, 11.3, and 13.2, for the damages incurred are a reasonable approximation of the anticipated harm or loss and acknowledges the difficulty of ------------- [*****] Indicates that material has been omitted and confidential treatment requested therefore. All such material has been filed separately with the Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934. estimation or calculation of actual damages, and each Party hereby waives the right to contest such payments as unenforceable, an unreasonable penalty, or otherwise.
Sample 1

Related to Damages Stipulation

  • Damages; Relief Termination of this Agreement shall not preclude either Party from claiming any other damages, compensation or relief that it may be entitled to upon such termination.

  • Arbitration, Damages, Warranties Notwithstanding any language to the contrary, no interpretation of this contract shall find that the State or its agencies have agreed to binding arbitration, or the payment of damages or penalties. Further, the State of Kansas and its agencies do not agree to pay attorney fees, costs, or late payment charges beyond those available under the Kansas Prompt Payment Act (K.S.A. 75-6403), and no provision will be given effect that attempts to exclude, modify, disclaim or otherwise attempt to limit any damages available to the State of Kansas or its agencies at law, including but not limited to the implied warranties of merchantability and fitness for a particular purpose.

  • Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.

  • INDEMNIFICATION AND PAYMENT OF DAMAGES BY BUYER Buyer will indemnify and hold harmless Sellers, and will pay to Sellers the amount of any Damages arising, directly or indirectly, from or in connection with (a) any Breach of any representation or warranty made by Buyer in this Agreement or in any certificate delivered by Buyer pursuant to this Agreement, (b) any Breach by Buyer of any covenant or obligation of Buyer in this Agreement, or (c) any claim by any Person for brokerage or finder's fees or commissions or similar payments based upon any agreement or understanding alleged to have been made by such Person with Buyer (or any Person acting on its behalf) in connection with any of the Contemplated Transactions.

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Damages for delay Subject to the provisions of Clause 12.4, if COD does not occur prior to the 91st day after the Scheduled Completion Date, unless the delay is on account of reasons solely attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority in a sum calculated at the rate of 0.1% (zero point one per cent) of the amount of Performance Security for delay of each day until COD is achieved.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE

  • INDEMNIFICATION AND PAYMENT OF DAMAGES BY SELLERS Sellers, jointly and severally, will indemnify and hold harmless Buyer, the Company, and their respective representatives, stockholders, controlling persons, and affiliates (collectively, the "Indemnified Persons") for, and will pay to the Indemnified Persons the amount of, any loss, liability, claim, damage (including incidental and consequential damages), expense (including costs of investigation and defense and reasonable attorneys' fees) or diminution of value, whether or not involving a third-party claim (collectively, "Damages"), arising, directly or indirectly, from or in connection with: (a) any and all loss, liability or damage suffered or incurred by Buyer in respect of any debt, obligation or liability of the Company or of Seller not disclosed in this Agreement, any of the Exhibits attached hereto, or in writing to Buyer prior to the Closing Date; (b) any breach of any representation or warranty made by Sellers in this Agreement, the Exhibits attached hereto, or any other certificate or document delivered by Sellers pursuant to this Agreement; (c) any breach of any representation or warranty made by Sellers in this Agreement as if such representation or warranty were made on and as of the Closing Date; (d) any Breach by either Seller of any covenant or obligation of such Seller in this Agreement; (e) any claim by any Person for brokerage or finder's fees or commissions or similar payments based upon any agreement or understanding alleged to have been made by any such Person with either Seller or the Company (or any person acting on their behalf) in connection with any of the transactions contemplated hereby. The remedies provided in this Section 9.2 will not be exclusive of or limit any other remedies that may be available to Buyer or the other Indemnified Persons.

  • Damages from Certain Causes Landlord shall not be liable or responsible to Tenant for any loss or damage to any property or person occasioned by theft, fire, act of God, public enemy, riot, strike, insurrection, war, act or omission of any party other than Landlord, any nuisance or interference caused or created by any property owner other than Landlord, requisition or order of governmental body or authority, court order or injunction, or any cause beyond Landlord’s control or for any damage or inconvenience which may arise through repair or alteration of any part of the Premises as required by this Lease.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!