Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Damages; Relief Termination of this Agreement shall not preclude either Party from claiming any other damages, compensation or relief that it may be entitled to upon such termination.
INDEMNIFICATION AND PAYMENT OF DAMAGES BY BUYER Buyer will indemnify and hold harmless Sellers, and will pay to Sellers the amount of any Damages arising, directly or indirectly, from or in connection with (a) any Breach of any representation or warranty made by Buyer in this Agreement or in any certificate delivered by Buyer pursuant to this Agreement, (b) any Breach by Buyer of any covenant or obligation of Buyer in this Agreement, or (c) any claim by any Person for brokerage or finder's fees or commissions or similar payments based upon any agreement or understanding alleged to have been made by such Person with Buyer (or any Person acting on its behalf) in connection with any of the Contemplated Transactions.
Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.
Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
INDEMNIFICATION AND PAYMENT OF DAMAGES BY SELLERS Sellers, jointly and severally, will indemnify and hold harmless Buyer, the Company, and their respective representatives, stockholders, controlling persons, and affiliates (collectively, the "Indemnified Persons") for, and will pay to the Indemnified Persons the amount of, any loss, liability, claim, damage (including incidental and consequential damages), expense (including costs of investigation and defense and reasonable attorneys' fees) or diminution of value, whether or not involving a third-party claim (collectively, "Damages"), arising, directly or indirectly, from or in connection with:
(a) any and all loss, liability or damage suffered or incurred by Buyer in respect of any debt, obligation or liability of the Company or of Seller not disclosed in this Agreement, any of the Exhibits attached hereto, or in writing to Buyer prior to the Closing Date;
(b) any breach of any representation or warranty made by Sellers in this Agreement, the Exhibits attached hereto, or any other certificate or document delivered by Sellers pursuant to this Agreement;
(c) any breach of any representation or warranty made by Sellers in this Agreement as if such representation or warranty were made on and as of the Closing Date;
(d) any Breach by either Seller of any covenant or obligation of such Seller in this Agreement;
(e) any claim by any Person for brokerage or finder's fees or commissions or similar payments based upon any agreement or understanding alleged to have been made by any such Person with either Seller or the Company (or any person acting on their behalf) in connection with any of the transactions contemplated hereby. The remedies provided in this Section 9.2 will not be exclusive of or limit any other remedies that may be available to Buyer or the other Indemnified Persons.
Expenses; Indemnity; Damage Waiver (a) The Borrower shall pay (i) all reasonable out-of-pocket expenses incurred by the Administrative Agent, and its Affiliates, including the reasonable fees, charges and disbursements of counsel for the Administrative Agent in connection with the syndication of the credit facilities provided for herein, the preparation and administration of this Agreement or any amendments, modifications or waivers of the provisions hereof (whether or not the transactions contemplated hereby or thereby shall be consummated) and (ii) all reasonable out-of-pocket expenses incurred by the Administrative Agent or any Lender, including the fees, charges and disbursements of any counsel for the Administrative Agent or any Lender, in connection with the enforcement or protection of its rights in connection with this Agreement, including its rights under this Section, or in connection with the Loans made hereunder, including in connection with any workout, restructuring or negotiations in respect thereof including, without limitation, actions in connection with this Agreement or the Loans, arising, occurring or continuing subsequent to the Maturity Date (other than any such expenses directly related to a court enforcement action in which the Borrower prevails on the merits in a final and nonappealable judgment).
(b) The Borrower shall indemnify the Administrative Agent and each Lender, and each Related Party of any of the foregoing Persons (each such Person being called an "Indemnitee") against, and hold each Indemnitee harmless from, any and all losses, claims, damages, liabilities and related expenses, including the fees, charges and disbursements of any counsel for any Indemnitee, incurred by or asserted against any Indemnitee arising out of, in connection with, or as a result of (i) the execution or delivery of this Agreement or any agreement or instrument contemplated hereby, the performance by the parties hereto of their respective obligations hereunder or the consummation of the Transactions or any other transactions contemplated hereby, (ii) any Loan or the use of the proceeds therefrom, (iii) any actual or alleged presence or release of Hazardous Materials on or from any property owned or operated by the Borrower or any of its Subsidiaries, or any Environmental Liability related in any way to the Borrower or any of its Subsidiaries, or (iv) any actual or prospective claim, litigation, investigation or proceeding relating to any of the foregoing, whether based on contract, tort or any other theory and regardless of whether any Indemnitee is a party thereto; provided that such indemnity shall not, as to any Indemnitee, be available to the extent that such losses, claims, damages, liabilities or related expenses are determined by a court of competent jurisdiction by final and nonappealable judgment to have resulted from the gross negligence or wilful misconduct of such Indemnitee.
(c) To the extent that the Borrower fails to pay any amount required to be paid by it to the Administrative Agent under paragraph (a) or (b) of this Section, each Lender severally agrees to pay to the Administrative Agent such Lender's Applicable Percentage (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Administrative Agent in its capacity as such.
(d) To the extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement or any agreement or instrument contemplated hereby, the Transactions, any Loan or the use of the proceeds thereof.
(e) All amounts due under this Section shall be payable promptly after written demand therefor.
Arbitration, Damages, Warranties Notwithstanding any language to the contrary, no interpretation of this contract shall find that the State or its agencies have agreed to binding arbitration, or the payment of damages or penalties. Further, the State of Kansas and its agencies do not agree to pay attorney fees, costs, or late payment charges beyond those available under the Kansas Prompt Payment Act (K.S.A. 75-6403), and no provision will be given effect that attempts to exclude, modify, disclaim or otherwise attempt to limit any damages available to the State of Kansas or its agencies at law, including but not limited to the implied warranties of merchantability and fitness for a particular purpose.
Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.
No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.
