Common use of Day’s Labor - Defined for Article 8, Public Works Clause in Contracts

Day’s Labor - Defined for Article 8, Public Works. (For Purposes of Article 8 of the Labor Law) No laborer, worker or mechanic in the employ of the Contractor, subcontractor or other person doing or contracting to do all or part of the work contemplated by the Contract shall be permitted or required to work more than eight hours in any one calendar day or more than five days in any one week except in cases of extraordinary emergency including fire, flood or danger to life or property. “Extraordinary emergency” shall be deemed to include situations in which sufficient laborers, workers and mechanics cannot be employed to carry on public work expeditiously as a result of such restrictions upon the number of hours and days of labor and the immediate commencement or prosecution or completion without undue delay of the public work is necessary in the judgment of the NYS Commissioner of Labor for the preservation of the Contract site or for the protection of the life and limb of the persons using the Contract site.

Day’s Labor - Defined for Article 8, Public Works. (For Purposes of Article 8 of the Labor Law) No laborer, worker or mechanic in the employ of the Contractorcontractor, subcontractor or other person doing or contracting to do all or part of the work contemplated by the Contract contract shall be permitted or required to work more than eight hours in any one calendar day or more than five days in any one week except in cases of extraordinary emergency including fire, flood or danger to life or property. “Extraordinary emergency” shall be deemed to include situations in which sufficient laborers, workers and mechanics cannot be employed to carry on public work expeditiously as a result of such restrictions upon the number of hours and days of labor and the immediate commencement or prosecution or completion without undue delay of the public work is necessary in the judgment of the NYS Commissioner of Labor for the preservation of the Contract contract site or for the protection of the life and limb of the persons using the Contract contract site.

Day’s Labor - Defined for Article 8, Public Works. (For Purposes of Article 8 of the Labor Law) No laborer, worker or mechanic in the employ of the Contractor, subcontractor or other person doing or contracting to do all or part of the work contemplated by the Contract shall be permitted or required to work more than eight hours in any one calendar day or more than five days in any one week except in cases of extraordinary emergency Emergency including fire, flood or danger to life or property. “Extraordinary emergencyEmergency” shall be deemed to include situations in which sufficient laborers, workers and mechanics cannot be employed to carry on public work expeditiously as a result of such restrictions upon the number of hours and days of labor and the immediate commencement or prosecution or completion without undue delay of the public work is necessary in the judgment of the NYS Commissioner of Labor for the preservation of the Contract site or for the protection of the life and limb of the persons using the Contract site.