Default by Developer; SCA’s Remedies Sample Clauses

Default by Developer; SCA’s Remedies. (a) If, after the Commencement of Construction of the School Base Building Work, (I) Developer fails to perform the work it is required to perform hereunder as a result of substantially all of the work on the School Unit at the time in question ceasing to be performed for more than forty-five (45) consecutive days, or (II) Developer fails to cause the School Base Building Work to be Substantially Completed no later than September 6, 2023 (provided, however, that any period during which Arbitration over whether Substantial Completion has occurred shall not be considered for purposes of the foregoing deadline to the extent the Arbitrator determines that Substantial Completion occurred on or prior to September 6, 2023), then provided (i) SCA is not then in default under this Agreement beyond any applicable notice and cure period and (ii) no Force Majeure or SCA Delay is then continuing, SCA shall have the right after ten (10) Business Days’ prior written notice to Developer, to (x) terminate this Agreement, the Master Lease and the Sublease and recover all Public School Project Costs paid to Developer and any other actual (but not consequential or punitive) damages incurred or suffered by SCA (it being understood that the termination of the Master Lease shall not be effective until immediately after SCA has been refunded and has recovered all of the foregoing amounts), (y) enforce specific performance, or (z) pursue any right or remedy available to SCA (but in no event shall SCA have the right to consequential or punitive damages), unless, in the case of clause (I) above, (A) work on the School Unit at the time in question has resumed during said ten (10) Business Day period and/or (B) (1) Developer has notified SCA during such ten (10) Business Day period that Developer intends to assign this Agreement pursuant to Section 15.07(a) within thirty (30) days of the date of such notice and such assignment becomes effective within such thirty (30) day period and (2) within five (5) Business Days after the effective date of such assignment, work on the School Unit at the time in question has resumed, it being understood that in either case of (A) or (B) above, SCA shall not be entitled to exercise any of the remedies set forth above. This paragraph shall survive the termination of this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to Default by Developer; SCA’s Remedies

  • Default Breach Remedies Notwithstanding anything to the contrary contained in Paragraph 13.1 or elsewhere in the Lease:

  • Events of Default by Tenant All covenants and agreements to be kept or performed by Tenant under this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any reduction of Rent. The occurrence of any of the following shall constitute a default of this Lease by Tenant:

  • Failure to Pursue Remedies The failure of any party to seek redress for violation of, or to insist upon the strict performance of, any provision of this Agreement shall not prevent a subsequent act, which would have originally constituted a violation, from having the effect of an original violation.

  • Events of Default Rights and Remedies Section 7.1 Events of Default Section 7.2 Rights and Remedies Section 7.3 Certain Notices

  • Events of Default Remedies If any of the following events (“Events of Default”) shall occur:

  • Event of Default Remedies If an Event of Default shall have occurred and be continuing, Secured Party may from time to time in its discretion, without limitation and without notice except as expressly provided below:

  • REMEDIES IN EVENT OF DEFAULT Upon the occurrence of an Event of Default, at the option of Lessor, which may be exercised at any time after an Event of Default shall have occurred, Lessor shall have all rights and remedies available to it, at law or in equity, including, without limitation, all of the rights and remedies under the Facility Lease and the other Lease Documents. Subject to the requirements f applicable law, all materials at that time on or near the Leased Property which are the property of Lessee and which are to be used in connection with the completion of the Project shall be subject to the Liens created by the Lease Documents. In addition to, and without limitation of, the foregoing, Lessor is authorized to charge all money expended for completion the Project against sums hereunder which have not already been advanced (even if the aggregate amount of such sums expended and all amounts previously advanced hereunder exceed the amount of the Project Funds which Lessor has agreed to advance hereunder); and Lessee agrees to pay to Lessor Rent under the Facility Lease calculated, in part, thereunder based upon all sums advanced hereunder, including, without limitation, all sums expended in good faith by Lessor in connection with the completion of the project), and, in addition thereto, Lessee agrees to pay to Lessor (as Rent under the Facility Lease), for services in connection with said completion of the Project, such additional sums as shall compensate Lessor for the time and effort Lessor and its employees shall have expended in connection therewith. Lessor is authorized, but not obligated in any event, to do all such things in connection with the construction of the Project as Lessor, in its sole and absolute discretion, may deem advisable, including, without limitation, the right to make any payments with respect to any obligation of Lessee to Lessor or to any other Person in connection with the completion of construction of the Project and to make additions and changes in the Project Plans, to employ contractors, subcontractors and agents and to take any and all such action, either in Lessor's own name or in the name of Lessee, and Lessee hereby grants Lessor an irrevocable power of attorney to act in its name in connection with the foregoing. This power of attorney, being coupled with an interest, shall be irrevocable until all of the Obligations are fully paid and performed and shall not be affected by any disability or incapacity which Lessee may suffer and shall survive the same. The power of attorney conferred on Lessor by the provisions of this Section 11 is provided solely to protect the interests of Lessor and shall not impose any duty on Lessor to exercise any such power and neither Lessor nor such attorney-in-fact shall be liable for any act, omission, error in judgment or mistake of law, except as the same may result from its gross negligence or wilful misconduct. In the event that Lessor takes possession of the Leased Property and assumes control of the project as aforesaid, it shall not be obligated to continue the construction of the Project and/or the operation of the Project for any period of time longer than Lessor shall see fit (in its sole and absolute discretion), and Lessor may thereafter, at any time, abandon its efforts and refuse to make further payments for the account of Lessee, whether or not the Project has been completed. In addition, at Lessor's option and without demand, notice or protest, the occurrence of any Event of Default shall also constitute a default under any one or more of the Related Party Agreements.

  • Defaults Remedies (a) It shall be an Event of Default:

  • Default by Seller Except as specifically provided elsewhere in this Contract, in the event that Seller fails to consummate this Contract or if Seller fails to perform any of Seller's other material obligations hereunder either prior to or at the Closing and such failure or refusal results from any reason other than the termination of this Contract by Purchaser pursuant to a right to terminate expressly set forth in this Contract or Purchaser's failure to perform Purchaser's obligations under this Contract, Purchaser may as its only remedy either (i) terminate this Contract by giving written notice thereof to Seller prior to or at the Closing, in which event Purchaser will be entitled to a return of the Deposit Note, whereupon neither party hereto will have any further rights or obligations hereunder, except (a) that Seller will authorize the Title Company to deliver to Purchaser the Deposit Note and Title Company will deliver the Deposit Note to Purchaser free of any claims by Seller or any other person with respect thereto, (b) that Seller shall reimburse Purchaser for its out of pocket costs associated with the negotiation and preparation of this Agreement and its examination of the Property, including, the fees and disbursements of its counsel, advisers, and agents, and (c) for provisions which survive Closing by their terms or (ii) enforce specific performance of Seller's duties and obligations under this Contract, provided that the right to enforce specific performance shall not require Seller to remove any title encumbrances placed on the Property after the Effective Date or require Seller to perform any covenant beyond the then current ability of Seller. In the event Purchaser fails to file an action for specific performance of this Contract on or before ninety (90) days after the date of such non-performance, Purchaser shall be deemed to have elected to proceed under clause (i) above and shall be deemed to have waived its right to enforce specific performance of this Contract.

  • Default Remedies Any one of the following occurrences shall constitute an ----------------- "EVENT OF DEFAULT" under this Note: (i) failure by the Maker to make any payment of principal or interest when the same becomes due and payable, said failure continuing for thirty (30) days or more; or (ii) if Maker shall fail to pay its debts, make an assignment for the benefit of its creditors, or shall commit an act of bankruptcy, or shall admit in writing its inability to pay its debts as they become due, or shall seek a composition, readjustment, arrangement, liquidation, dissolution or insolvency proceeding under any present or future statute or law, or shall file a petition under any chapter of federal Bankruptcy Code or any similar law, state or federal, now or hereafter existing, or shall become "insolvent" as that term is generally defined under the Federal Bankruptcy Code, or shall in any involuntary bankruptcy case commenced against it file an answer admitting insolvency or inability to pay its debts as they become due, or shall fail to obtain a dismissal of such case within sixty (60) days after its commencement or convert the case from one chapter of the Federal Bankruptcy Code to another chapter, or be the subject of an order for relief in such bankruptcy case, or to be adjudged a bankruptcy or insolvent, or shall have a custodian, trustee or receiver appointed for, or have any court take jurisdiction of its property, or any part thereof, in any proceeding for the purpose of reorganization, arrangement, dissolution or liquidation, and such custodian, trustee, liquidator or receiver shall not be discharged, or such jurisdiction shall not be relinquished, vacated or stayed within sixty (60) days of the appointment. Upon occurrence of an Event of Default hereunder, the entire outstanding principal balance and any unpaid interest then accrued under this Note, shall at the option of the Payee hereof and without demand or notice of any kind to the undersigned or any other person (including, but not limited to, any guarantor now or hereafter existing), immediately become and be due and payable in full. In such event, Payee shall have and may exercise any and all rights and remedies available at law or in equity.

Time is Money Join Law Insider Premium to draft better contracts faster.