Construction Loan Subject to the terms and conditions of this Agreement and in reliance upon the representations and warranties set forth in this Agreement, the Lender has agreed to lend to Borrower and Borrower has agreed to borrow from Lender the lesser of: (i) $27,000,000.00; or (ii) 55% of the Project Costs. Such amount shall be loaned by Lender pursuant to the terms and conditions set forth in this Agreement and the First Supplement to this Agreement.
No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Interest Subsidy and Special Allowance Payments and Rebate Fees The Seller shall be entitled to all Interest Subsidy Payments and Special Allowance Payments on each Additional Loan or Substituted Loan accruing up to but not including the related Subsequent Cutoff Date and shall be responsible for the payment of any rebate fees applicable to such Purchased Loans subject to the related Xxxx of Sale accruing up to but not including the related Subsequent Cutoff Date. The Purchaser and the Eligible Lender Trustee on behalf of the Purchaser shall be entitled to all Special Allowance Payments and Interest Subsidy Payments accruing from the related Subsequent Cutoff Date with respect to the Additional Loans or Substituted Loans, and shall be responsible for the payment of any rebate fees applicable to the Additional Loans accruing from the date of the related Subsequent Cutoff Date.
Payment of Principal, Interest, Escrow Items, Prepayment Charges, and Late Charges Borrower will pay each Periodic Payment when due. Borrower will also pay any prepayment charges and late charges due under the Note, and any other amounts due under this Security Instrument. Payments due under the Note and this Security Instrument must be made in U.S. currency. If any check or other instrument received by Lender as payment under the Note or this Security Instrument is returned to Lender unpaid, Lender may require that any or all subsequent payments due under the Note and this Security Instrument be made in one or more of the following forms, as selected by Lender: (a) cash; (b) money order; (c) certified check, bank check, treasurer’s check, or cashier’s check, provided any such check is drawn upon an institution whose deposits are insured by a U.S. federal agency, instrumentality, or entity; or (d) Electronic Fund Transfer. Payments are deemed received by Lender when received at the location designated in the Note or at such other location as may be designated by Lender in accordance with the notice provisions in Section 16. Lender may accept or return any Partial Payments in its sole discretion pursuant to Section 2. Any offset or claim that Borrower may have now or in the future against Lender will not relieve Borrower from making the full amount of all payments due under the Note and this Security Instrument or performing the covenants and agreements secured by this Security Instrument.
Servicing Agreement General Summary The Sellers and the Purchasers intend this Agreement to amend and restate that certain “Servicing Agreement,” dated March 23, 2021, for purposes of the Purchase Agreement and wish to set forth herein the terms upon which each Purchaser will, to the fullest extent permitted by applicable Law and the applicable Corporate Trust Contract, and subject to the applicable provisions of this Agreement, assume the responsibility (as agent of the applicable Seller) to supervise, manage, administer and otherwise discharge the duties of the applicable Seller in a Corporate Trust Capacity under (a) any Restricted Appointment and (b) any Excluded Appointment (collectively, the “Serviced Appointments”), and the Purchasers will discharge and perform when due, and indemnify the Sellers for, the Assumed Servicing Liabilities.
Conditions Precedent to the Initial Extension of Credit The obligation of each Lender to make the initial extensions of credit provided for hereunder is subject to the fulfillment, to the satisfaction of Agent and each Lender, of each of the conditions precedent set forth on Schedule 3.1 to this Agreement (the making of such initial extensions of credit by a Lender being conclusively deemed to be its satisfaction or waiver of the conditions precedent).
Refinancing Preparation Advance If the Financing Agreement provides for the repayment out of the proceeds of the Financing of an advance made by the Association or the Bank (“Preparation Advance”), the Association shall, on behalf of the Recipient, withdraw from the Financing Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Financing Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Association shall pay the amount so withdrawn to itself or the Bank, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.” 2. Paragraph (i) of Section 6.02 is modified to read as follows: “Section 6.02.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Initial Advance Borrower shall have delivered to Lender each of the following, in form and substance satisfactory to Lender (the date on which each of the following shall have been so delivered is referred to herein as the “Effective Date”): (a) executed originals of the Loan Documents and all other documents and instruments reasonably required by Lender to effectuate the transactions contemplated hereby or to create and perfect the Liens of Lender with respect to all Collateral, in all cases in form and substance reasonably acceptable to Lender; (b) certified copy of resolutions of Borrower’s board of directors evidencing approval of (i) the Loan and other transactions evidenced by the Loan Documents; and (ii) the Warrant and transactions evidenced thereby; (c) certified copies of the Certificate of Incorporation and the Bylaws, as amended through the Closing Date, of Borrower; (d) a certificate of good standing for Borrower from its state of incorporation and similar certificates from all other jurisdictions in which it does business and where the failure to be qualified would have a Material Adverse Effect; (e) a certificate of incumbency as to each officer of Borrower who is authorized to execute the Loan Documents, the Warrant, and all other documents and instruments to be delivered pursuant to the Loan Documents and the Warrant on behalf of Borrower, including, without limitation, the chief financial officer of Borrower; (f) payment of the Facility Charge and reimbursement of Lender’s current expenses reimbursable pursuant to this Agreement, which amounts may be deducted from the initial Advance; (g) Landlord Consents or Bailee Agreements, as applicable, for the premises where the Financed Equipment will, upon completion of transit, be located; provided, that up to $3,750,000 of the initial Advance may be used for the purchase of International Based Financed Equipment without delivering to Lender, prior to the disbursement of such Advance, any Landlord Consents in respect of the premises in the continental United States where such International Based Financed Equipment may be located temporarily, so long as (i) prior to the disbursement of such Advance, one or more Bailee Agreements, as applicable, are delivered in respect of the foreign premises where such International Based Financed Equipment will be located upon completion of transit, and (ii) within 90 days of the Effective Date (or any subsequent Advance Date with respect to any International Based Financed Equipment not financed on the Effective Date), such International Based Financed Equipment is relocated to such foreign premises; (h) a Consent Letter from each Incumbent Lender; (i) a Release Letter from each Incumbent Lender with respect to the Financed Equipment purchased with the proceeds of the initial Advance; and (j) such other documents as Lender may reasonably request.
