Common use of Definition of Claim Clause in Contracts

Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the Owner as a separate demand by the Contractor for: (1) a time extension including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract; (2) payment by the District of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract and payment for which is not otherwise expressly provided for or to which the Contractor is not otherwise entitled to; or (3) an amount of payment disputed by the Owner.

Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the Owner District as a separate demand by the Contractor for: (1) a time extension extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract; (2) payment by the District of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract and payment for which is not otherwise expressly provided for or to which the Contractor is not otherwise entitled to; or (3) an amount of payment disputed by the Owner.)

Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the Owner as a separate demand by the Contractor for: for (1) a time extension includingextension, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract; (2) payment by the District of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract CONTRACT and payment for of which is not otherwise expressly provided for or to which the Contractor claimant is not otherwise entitled to; , or (3) an and amount the payment of payment which is disputed by the Owner.

Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the Owner District as a separate demand by the Contractor for: (1) a time extension extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract; (2) payment by the District of money or damages arising from Work done by by, or on behalf of of, the Contractor pursuant to the Contract and payment for which is not otherwise expressly provided for or to which the Contractor is not otherwise entitled to; or (3) an amount of payment disputed by the Owner.payment