Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.
No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Expenses; Indemnity; Damage Waiver (a) The Borrower shall pay (i) all reasonable out-of-pocket expenses incurred by the Administrative Agent, and its Affiliates, including the reasonable fees, charges and disbursements of counsel for the Administrative Agent in connection with the syndication of the credit facilities provided for herein, the preparation and administration of this Agreement or any amendments, modifications or waivers of the provisions hereof (whether or not the transactions contemplated hereby or thereby shall be consummated) and (ii) all reasonable out-of-pocket expenses incurred by the Administrative Agent or any Lender, including the fees, charges and disbursements of any counsel for the Administrative Agent or any Lender, in connection with the enforcement or protection of its rights in connection with this Agreement, including its rights under this Section, or in connection with the Loans made hereunder, including in connection with any workout, restructuring or negotiations in respect thereof including, without limitation, actions in connection with this Agreement or the Loans, arising, occurring or continuing subsequent to the Maturity Date (other than any such expenses directly related to a court enforcement action in which the Borrower prevails on the merits in a final and nonappealable judgment). (b) The Borrower shall indemnify the Administrative Agent and each Lender, and each Related Party of any of the foregoing Persons (each such Person being called an "Indemnitee") against, and hold each Indemnitee harmless from, any and all losses, claims, damages, liabilities and related expenses, including the fees, charges and disbursements of any counsel for any Indemnitee, incurred by or asserted against any Indemnitee arising out of, in connection with, or as a result of (i) the execution or delivery of this Agreement or any agreement or instrument contemplated hereby, the performance by the parties hereto of their respective obligations hereunder or the consummation of the Transactions or any other transactions contemplated hereby, (ii) any Loan or the use of the proceeds therefrom, (iii) any actual or alleged presence or release of Hazardous Materials on or from any property owned or operated by the Borrower or any of its Subsidiaries, or any Environmental Liability related in any way to the Borrower or any of its Subsidiaries, or (iv) any actual or prospective claim, litigation, investigation or proceeding relating to any of the foregoing, whether based on contract, tort or any other theory and regardless of whether any Indemnitee is a party thereto; provided that such indemnity shall not, as to any Indemnitee, be available to the extent that such losses, claims, damages, liabilities or related expenses are determined by a court of competent jurisdiction by final and nonappealable judgment to have resulted from the gross negligence or wilful misconduct of such Indemnitee. (c) To the extent that the Borrower fails to pay any amount required to be paid by it to the Administrative Agent under paragraph (a) or (b) of this Section, each Lender severally agrees to pay to the Administrative Agent such Lender's Applicable Percentage (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Administrative Agent in its capacity as such. (d) To the extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement or any agreement or instrument contemplated hereby, the Transactions, any Loan or the use of the proceeds thereof. (e) All amounts due under this Section shall be payable promptly after written demand therefor.
Actual Damages Contractor is liable to CMHA for all actual and direct damages caused by Contractor’s default. In the event Contractor fails to provide services or material as provided for in the Contract Documents, CMHA may substitute the services and/or material from a third party. CMHA may recover the costs associated with acquiring substitute services and/or materials, less any expense or costs saved by Contractor’s default, from Contractor.
Termination Damages If the Term of this Lease is terminated for default, unless and until Landlord elects lump sum liquidated damages described in the next paragraph, Tenant covenants, as an additional, cumulative obligation after any such termination, to pay punctually to Landlord all the sums and perform all of its obligations in the same manner as if the Term had not been terminated. In calculating such amounts Tenant will be credited with the net proceeds of any rent then actually received by Landlord from a reletting of the Premises after deducting all Rent that has not then been paid by Tenant, provided that Tenant shall never be entitled to receive any portion of the re-letting proceeds, even if the same exceed the Rent originally due hereunder.
Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Monetary Damages In the event that the Partnership breaches its obligations set forth in Article 2, Article 3, or Article 6 with respect to a Protected Partner the Protected Partner’s sole right shall be to receive from the Partnership, and the Partnership shall pay to such Protected Partner as damages, an amount equal to: (a) in the case of a violation of Articles 3 or 0, xxx xxxxxxxxx xxxxxxx, xxxxx and local income taxes incurred by the Protected Partner or an Indirect Owner as a result of the income or gain allocated to, or otherwise recognized by, such Protected Partner with respect to its Units by reason of such breach; (b) in the case of a violation of Article 0, xxx xxxxxxxxx xxxxxxx xxxxx, and local income taxes incurred by the Protected Partner or an Indirect Owner with respect the Excess Protected Gain incurred with respect to the Gain Limitation Property that is allocable to such Protected Partner under the Partnership Agreement and Section 2.3 hereof (computed without regard to the principles set forth in the parenthetical in the first paragraph of Section 2.1); plus in the case of either (a) or (b), an amount equal to the aggregate federal, state, and local income taxes payable by the Protected Partner or an Indirect Owner as a result of the receipt of any payment required under this Section 4.1. For purposes of computing the amount of federal, state, and local income taxes required to be paid by a Protected Partner (or Indirect Owner), (i) any deduction for state income taxes payable as a result thereof actually allowed in computing federal income taxes shall be taken into account, and (ii) a Protected Partner’s (or Indirect Owner’s) tax liability shall be computed using the highest federal, state and local marginal income tax rates that would be applicable to such Protected Partner’s (or Indirect Owner’s) taxable income (taking into account the character and type of such income or gain) for the year with respect to which the taxes must be paid, without regard to any deductions, losses or credits that may be available to such Protected Partner (or Indirect Owner) that would reduce or offset its actual taxable income or actual tax liability if such deductions, losses or credits could be utilized by the Protected Partner (or Indirect Owner) to offset other income, gain or taxes of the Protected Partner(or Indirect Owner), either in the current year, in earlier years, or in later years).
