Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Delay of Payment when Payment Date is Not a Business Day If the due date for a payment on a Note as provided in this Indenture is not a Business Day, then, notwithstanding anything to the contrary in this Indenture or the Notes, such payment may be made on the immediately following Business Day and no interest will accrue on such payment as a result of the related delay. Solely for purposes of the immediately preceding sentence, a day on which the applicable place of payment is authorized or required by law or executive order to close or be closed will be deemed not to be a “Business Day.”
Obligation to Pay Royalties A royalty is due Stanford under this Agreement for any activity conducted under the licenses granted. For convenience’s sake, the amount of that royalty is calculated using Net Sales. Nonetheless, if certain Licensed Products are made, used, imported, or offered for sale before the date this Agreement terminates, and those Licensed Products are sold after the termination date, ImmuMetrix will pay Stanford an earned royalty for its exercise of rights based on the Net Sales of those Licensed Products.
Default Payment Following the occurrence and during the continuance of an Event of Default, the Holder, at its option, may demand repayment in full of all obligations and liabilities owing by Company to the Holder under this Note, the Purchase Agreement and/or any other Related Agreement and/or may elect, in addition to all rights and remedies of the Holder under the Purchase Agreement and the other Related Agreements and all obligations and liabilities of the Company under the Purchase Agreement and the other Related Agreements, to require the Company to make a Default Payment (“Default Payment”). The Default Payment shall be 130% of the outstanding principal amount of the Note, plus accrued but unpaid interest, all other fees then remaining unpaid, and all other amounts payable hereunder. The Default Payment shall be applied first to any fees due and payable to the Holder pursuant to this Note, the Purchase Agreement, and/or the other Related Agreements, then to accrued and unpaid interest due on this Note and then to the outstanding principal balance of this Note. The Default Payment shall be due and payable immediately on the date that the Holder has exercised its rights pursuant to this Section 2.3.
Payment of Reimbursement Amount To effect the expense reimbursement provided for in this Agreement, the Fund may offset the appropriate Reimbursement Amount against the management fees, Rule 12b-1 fees and/or shareholder servicing fees payable under the Investment Management Agreement, Rule 12b-1 Plan and/or the Shareholder Servicing Agreement. Alternatively, the Reimbursement Amount shall be paid directly by IICO, IDI and/or WISC. Such offset shall be taken, or such direct payment shall be paid, two times per year within 30 days following the date of a Fund’s applicable semi-annual or annual reporting period.
Payment of Additional Interest (a) Under certain circumstances the Company will be obligated to pay certain additional amounts of interest to the Holders of certain Initial Notes, as more particularly set forth in such Initial Notes.
Delay Not a Waiver Neither any failure nor any delay on the part of Lender in insisting upon strict performance of any term, condition, covenant or agreement, or exercising any right, power, remedy or privilege hereunder, or under the Note or under any other Loan Document, or any other instrument given as security therefor, shall operate as or constitute a waiver thereof, nor shall a single or partial exercise thereof preclude any other future exercise, or the exercise of any other right, power, remedy or privilege. In particular, and not by way of limitation, by accepting payment after the due date of any amount payable under this Agreement, the Note or any other Loan Document, Lender shall not be deemed to have waived any right either to require prompt payment when due of all other amounts due under this Agreement, the Note or the other Loan Documents, or to declare a default for failure to effect prompt payment of any such other amount.