Delayed payments The Parties hereto agree that payments due from one Party to the other Party under the provisions of this Agreement shall be made within the period set forth therein, and if no such period is specified, within 30 (thirty) days of receiving a demand along with the necessary particulars. Unless otherwise specified in this Agreement, in the event of delay beyond such period, the defaulting Party shall pay interest for the period of delay calculated at a rate equal to 5% (five per cent) above the Bank Rate, and recovery thereof shall be without prejudice to the rights of the Parties under this Agreement including Termination thereof.
Returned Payment Fee If your account is subject to a Returned Payment Fee, the fee will be charged to your account when a payment is returned for any reason.
E-PAYMENT Contractor agrees to accept all payments in United States currency via the State of Mississippi’s electronic payment and remittance vehicle. The agency agrees to make payment in accordance with Mississippi law on “Timely Payments for Purchases by Public Bodies,” which generally provides for payment of undisputed amounts by the agency within forty-five (45) days of receipt of invoice. Mississippi Code Annotated § 31-7-301 et seq.
Down Payment The Mortgagor has contributed at least 5% of the purchase price for the Mortgaged Property with his/her own funds.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Non-Payment The Borrower or any other Loan Party fails to pay (i) when and as required to be paid herein, any amount of principal of any Loan or any L/C Obligation, or (ii) within three days after the same becomes due, any interest on any Loan or on any L/C Obligation, or any fee due hereunder, or (iii) within five days after the same becomes due, any other amount payable hereunder or under any other Loan Document; or
Termination Payment The final payment delivered to the Certificateholders on the Termination Date pursuant to the procedures set forth in Section 9.01(b).
PRE-PAYMENT The Tenant shall: (check one) ☐ - Pre-Pay Rent in the amount of $[PRE-PAY RENT AMOUNT] for the term starting on [START DATE] and ending on [END DATE]. The Pre-Payment of Rent shall be due upon the execution of this Agreement. ☐ - Not be required to Pre-Pay Rent.
Interim payment At the end of each of the periods indicated in Annex I the Contractor shall submit to the Agency a formal request for payment accompanied by those of the following documents which are provided for in the Special Conditions: ➢ an interim technical report in accordance with the instructions laid down in Xxxxx X; ➢ the relevant invoices indicating the reference number of the Contract and of the order or specific contract to which they refer;
Upfront Payment Upon the execution of this Agreement, the Lessee shall pay to the Lessor the following: (check one) ☐ - First Month’s Rent of: _ Dollars ($ _) ☐ - Last Month’s Rent of: ___ _ Dollars ($ _) ☐ - Security Deposit of: _ _ Dollars ($ _)
