Common use of DELAYS / DISRUPTIONS Clause in Contracts

DELAYS / DISRUPTIONS. The contractor shall coordinate the work effort with the NSA Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than those indicated above are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted.

DELAYS / DISRUPTIONS. The contractor shall coordinate the work effort with the NSA Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or lessless period. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than those indicated above are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted.

DELAYS / DISRUPTIONS. The contractor Contractor shall coordinate the work effort with the NSA Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than those indicated above are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted.