Schedule. The Work shall be performed as expeditiously as possible in conformity with the schedule requirements contained herein and in the Statement of Work. The draft and final versions of all deliverables shall be submitted by the dates specified in the Exhibit A Schedule and Project Period noted in Item No. 7 of this Agreement. It is understood and agreed that the delivery of the draft and final versions of such deliverables by the Contractor shall occur in a timely manner and in accordance with the requirements of the Exhibit A Schedule.
Schedule. The Design Professional shall provide the services required by this Contract in conformance with the approved Preliminary Design and Construction Schedule. The Design Professional agrees to complete the Construction Documents not later than or not later than calendar days following execution of this Contract. Individual Milestones for completion of construction documents will be mutually agreed by the Owner and Design Professional.
Schedule. The CONTRACTOR shall commence services on December 1, 2020 and complete all services by November 30, 2021 Reports and other items shall be delivered or completed in accordance with the detailed schedule set forth in Exhibit “A”. Any order issued during the effective date of this contract, but not completed within that period, shall be completed by the CONTRACTOR within the time specified in the order. The contract shall govern the CONTRACTOR and the COUNTY’S rights and obligations with respect to the extent as if the order were completed during the contract’s performance period.
Schedule. The components of the project described in the Scope of Services shall be completed according to Term, above.
Schedule a. Time is and shall remain of the essence in the performance of this Contract and Seller shall strictly adhere to the schedules specified in this Contract. Failure to deliver in accordance with the Contract schedule, if unexcused, shall constitute a material breach of this Contract. In the event of any anticipated or actual delay, including but not limited to delays attributed to labor disputes, Seller shall: (i) promptly notify Buyer in writing of the reasons for the delay and the actions being taken to overcome or minimize the delay; (ii) provide Buyer with a written recovery schedule; and (iii), if requested by Buyer, ship via air or expedited routing, at no additional cost to Buyer, to avoid or minimize delay to the maximum extent possible.
b. Seller shall not deliver Services prior to the scheduled delivery dates unless authorized in writing by Xxxxx’s Authorized Procurement Representative.
Schedule. Developer shall provide to District, Construction Manager, and Architect a schedule in conformance with the Contract Documents and as required in these Construction Provisions.
Schedule. The Services will be undertaken in a manner that ensures the Project is completed timely and efficiently in accordance with the Project.
Schedule. The schedule for design and development of the Tenant Improvements, including the time periods for preparation and review of construction documents, approvals and performance, shall be in accordance with a schedule to be prepared by Tenant (the "Schedule"). Tenant shall prepare the Schedule so that it is a reasonable schedule for the completion of the Tenant Improvements. The Schedule shall clearly identify all activities requiring Landlord participation. As soon as the Schedule is completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such Schedule shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord disapproves the Schedule, then Landlord shall notify Tenant in writing of its objections to such Schedule, and the parties shall confer and negotiate in good faith to reach agreement on the Schedule. The Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as provided in this Work Letter.
Schedule. The Review Board shall assume control of the arbitration process and shall schedule all events as expeditiously as possible. The Arbitration Hearing shall commence within ninety (90) Business Days after receipt of the Notice of Dispute by the Arbitration Administrator.
Schedule. The Contractor submitted its Schedule to the Authority with its Task Order proposal. It is the Contractor’s responsibility to satisfactorily complete the entire Project within the time specified. The Contractor shall prosecute the Work so that the actual Work completed shall be not less than required by the approved Project Schedule. If the rate of progress is such that the total amount of Work accomplished by the Contractor within any time mentioned in the approved Project Schedule is less than the amount specified to be completed within such time, then the Authority may declare this Contract or any portion thereof in default as provided in Article XI, Section 2 “Termination for Convenience” herein. The Contractor shall commence performance of its obligations under this Contract no later than one week after the Notice to Proceed is delivered by the Authority. Contractor may, with the approval of the Authority, adjust the Project Schedule as the Work proceeds. Contractor and its subcontractors shall furnish sufficient shift work and overtime as necessary to not exceed, nor permit its Subcontractors to exceed, the time limits established by this Project Schedule, as approved by the Authority, except for reasonable cause as determined by the Authority. The Contractor and its Subcontractors shall anticipate and furnish sufficient coordination, scheduling, supervision, labor, overtime labor and shift work to complete the Work, including remedial work, if necessary, prior to the Final Completion Date, without additional compensation. It is understood and agreed that certain milestone dates included in the Contractor's schedule will be relied upon by the Authority and the Contractor has included in the Guaranteed Maximum Price all costs for shift work, overtime work, additional forces and resources to achieve those milestone dates. The Contractor understands and agrees that the Facility will remain occupied and in use in certain areas and at times as determined by the Authority and Metra throughout the performance of the Work and the Contractor shall on a day-to-day basis coordinate its Work to the satisfaction of the Authority in accordance with the Work Day Schedule and the continuing operations of the Authority. The Contractor shall plan and coordinate its Work under this Contract to avoid conflicts with other users, lessees, licensees and patrons of the Facility. Contractor must coordinate its Work with the Authority, the Authority's other contractors and su...
