Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.
Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.
Suspension of Work Authorization DocuSign Envelope ID: F977C999-9391-4B1E-8882-3E74EBE07795
NO CESSATION OF WORK 6.01 Neither the Union nor any employee shall take part in or call or encourage any strike, sit-down, slow-down, or any suspension of work against the Company which shall in any way affect the operations of the Company; nor shall the Company engage in any lockout at its Plants or Mines in the Sudbury District.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Effect of Force Majeure Event If either party to this contract cannot meet an obligation under this contract because of an event outside the control of that party (‘a force majeure event’): (a) the obligation, other than an obligation to pay money, is suspended to the extent it is affected by the force majeure event for as long as the force majeure event continues; and (b) the affected party must use its best endeavours to give the other party prompt notice of that fact including full particulars of the event, an estimate of its likely duration, the extent to which the affected party’s obligations are affected and the steps being taken to remove, overcome or minimise those effects.
Termination of Licenses Subject to Clause 33.3 (Licence granted by the Supplier: Supplier Background IPR), all licences granted pursuant to Clause 33 (Intellectual Property Rights) (other than those granted pursuant to Clause 33.6 (Third Party IPR) and 33.7 (Licence granted by the Customer)) shall survive the Call Off Expiry Date. The Supplier shall, if requested by the Customer in accordance with Call Off Schedule 9 (Exit Management), grant (or procure the grant) to the Replacement Supplier of a licence to use any Supplier Background IPR and/or Third Party IPR on terms equivalent to those set out in Clause 33.3 (Licence granted by the Supplier: Supplier Background IPR) subject to the Replacement Supplier entering into reasonable confidentiality undertakings with the Supplier. The licence granted pursuant to Clause 33.7 (Licence granted by the Customer ) and any sub-licence granted by the Supplier in accordance with Clause 33.7.1 (Licence granted by the Customer) shall terminate automatically on the Call Off Expiry Date and the Supplier shall: immediately cease all use of the Customer Background IPR and the Customer Data (as the case may be); at the discretion of the Customer, return or destroy documents and other tangible materials that contain any of the Customer Background IPR and the Customer Data, provided that if the Customer has not made an election within six months of the termination of the licence, the Supplier may destroy the documents and other tangible materials that contain any of the Customer Background IPR and the Customer Data (as the case may be); and ensure, so far as reasonably practicable, that any Customer Background IPR and Customer Data that are held in electronic, digital or other machine-readable form ceases to be readily accessible from any computer, word processor, voicemail system or any other device of the Supplier containing such Customer Background IPR and/or Customer Data. The Supplier shall, during and after the Call Off Contract Period, on written demand, indemnify the Customer against all Losses incurred by, awarded against, or agreed to be paid by the Customer (whether before or after the making of the demand pursuant to the indemnity hereunder) arising from an IPR Claim. If an IPR Claim is made, or the Supplier anticipates that an IPR Claim might be made, the Supplier may, at its own expense and sole option, either: procure for the Customer the right to continue using the relevant item which is subject to the IPR Claim; or replace or modify the relevant item with non-infringing substitutes provided that: the performance and functionality of the replaced or modified item is at least equivalent to the performance and functionality of the original item; the replaced or modified item does not have an adverse effect on any other Goods and/or Services; there is no additional cost to the Customer; and the terms and conditions of this Call Off Contract shall apply to the replaced or modified Goods and/or Services. If the Supplier elects to procure a licence in accordance with Clause 33.9.2(a) or to modify or replace an item pursuant to Clause 33.9.2(b), but this has not avoided or resolved the IPR Claim, then: the Customer may terminate this Call Off Contract by written notice with immediate effect; and without prejudice to the indemnity set out in Clause 33.9.1, the Supplier shall be liable for all reasonable and unavoidable costs of the substitute goods and/or services including the additional costs of procuring, implementing and maintaining the substitute items.
