Delays Not Caused by Lessee Sample Clauses

Delays Not Caused by Lessee. If the delay in tender of possession relates to the 4th Floor Premises and Section 2.3.1.2 does not apply, then (i) the Lease Term and Lessee’s obligation to pay Base Rental or other rental pursuant hereto shall commence when Lessor Substantially Completes Lessor’s Work for the 4th Floor Premises and tenders possession thereof to Lessee (regardless of whether Lessee actually takes possession), and (ii) the Termination Date shall be advanced by the number of days that commencement of the term hereof was so delayed. If the delay in tender of possession relates to the 3rd Floor Phase II Premises and does not result from Delays Caused by Lessee, then (i) with respect to the 3rd Floor Phase II Premises, the Lease Term and Lessee’s obligation to pay Base Rental or other rental pursuant hereto shall commence when Lessor Substantially Completes Lessor’s Work for the 3rd Floor Phase II Premises and tenders possession thereof to Lessee (regardless of whether Lessee actually takes possession). If the delay in tender of possession relates to the 3rd Floor Phase III Premises and does not result from Delays Caused by Lessee, then (i) with respect to the 3rd Floor Phase III Premises, the Lease Term and Lessee’s obligation to pay Base Rental or other rental pursuant hereto shall commence when Lessor Substantially Completes Lessor’s Work for the 3rd Floor Phase III Premises and tenders possession thereof to Lessee (regardless of whether Lessee actually takes possession). If Lessor, however, is unable to tender possession of the 4th Floor Premises to Lessee on or before one hundred twenty (120) days after the Commencement Date for the 4th Floor Premises set forth in the Basic Lease Information for reasons other than Delays Caused by Lessee (in which event Section 2.3.1.2 below shall apply) and/or force majeure events described in Article 26 (in which event said Article shall apply with respect to such delay), then Lessor shall not be in breach of this Lease, but Lessee shall be entitled to terminate this Lease by written notice to Lessor given within ten (10) days after the expiration of said 120-day period, which shall constitute Lessee’s sole right and remedy with respect thereto.
Sample 1
AutoNDA by SimpleDocs

Related to Delays Not Caused by Lessee

  • Termination by Lessee Subject to Subparagraph 18D, and without limiting any other rights and remedies to which Lessee may be entitled by common law, statutory law, or as elsewhere provided in this Lease, this Lease may be terminated by Lessee at any time after the happening, and during the existence, of one of more of the following events: i. The City’s permanent abandonment of the Premises at the Airport; ii. The lawful assumption by the United States Government, or any authorized agency thereof, of the operation, control, or use of the Airport, or any substantial part or parts thereof, that substantially restricts any sublessee from operating for at least one hundred fifty (150) calendar days; iii. The issuance by any court of competent jurisdiction of an injunction that prevents or restrains the use of the Airport or the Premises, that continues for at least one hundred fifty (150) calendar days; iv. The default by the City in the performance of any covenant or obligation on the part of the City to be performed, and the failure of the City to remedy the default for sixty (60) calendar days after receipt from Lessee of written notice to remedy the same; or v. Lessee’s decision to terminate the Lease as provided in Paragraph 11(B) of the Lease.

  • Termination by Lessor Lessor may terminate the lease at any time if any of the following shall happen:

  • Termination by Landlord If the Resident fails to adhere to the Community Standards and House Rules, or fails to perform and observe any of the terms or conditions of this Residence Agreement, the Landlord, at its option and in its sole discretion, may terminate the Term created by this Residence Agreement upon giving the Resident written notice of the Landlord’s intention to do so, to take effect within no less than forty-eight (48) hours from receipt of a Notice to Vacate from the Landlord. Notwithstanding the foregoing, a Resident may be immediately evicted from the Premises and Residence for reasons including but not limited to assault of any kind, any offence resulting in a criminal charge, any destruction of property, or if the Resident is deemed a safety concern for the community. The Resident is liable to pay all legal costs incurred by the Landlord in enforcing the provisions of this Residence Agreement including obtaining possession of the Premises.

  • Termination by Contractor Contractor may, at its option, terminate this Contract upon the failure of MPS to pay any amount, which may become due hereunder for a period of sixty (60) days following submission of appropriate billing and supporting documentation. Upon said termination, Contractor shall be paid the compensation due for all services rendered through the date of termination including any retainage.

  • Termination by Tenant In the event that the destruction to the Premises cannot be restored as required herein under applicable laws and regulations within two hundred seventy (270) days of the damage or casualty, notwithstanding the availability of insurance proceeds, Tenant shall have the right to terminate this Lease by giving the Landlord notice thereof within thirty (30) days of date of the occurrence of such casualty specifying the date of termination which shall not be less than thirty (30) days nor more than sixty (60) days following the date on which such notice of termination is given. In the event of the giving of such notice of termination, this Lease shall expire and all interest of Tenant in the Premises shall terminate on the date so specified in such notice and the Rent, reduced by any proportionate reduction in Rent as provided for in Section 18.1 above, shall be paid to the date of such termination.

  • TERMINATION FOR CAUSE BY CONTRACTOR 4.06.1 Contractor may terminate its performance under this Agreement only if the City defaults and fails to cure the default after receiving written notice of it. Default by the City occurs if the City fails to perform one or more of its material duties under this Agreement. If a default occurs and Contractor wishes to terminate the Agreement, then Contractor must deliver a written notice to the Director describing the default and the proposed termination date. The date must be at least 30 days after the Director receives the notice. Contractor, at its sole option, may extend the proposed termination date to a later date. If the City cures the default before the proposed termination date, then the proposed termination is ineffective. If the City does not cure the default before the proposed termination date, then Contractor may terminate its performance under this Agreement on the termination date

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Where by reason of the provisions of paragraph 1 a person other than an individual is a resident of both Contracting States, then it shall be deemed to be a resident only of the State in which its place of effective management is situated.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!