Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Procedure as to Rejected Goods On receipt of notification of rejection, Seller will immediately arrange to receive back the goods for shipment and return. However, within 5 days, Seller may have an agent inspect such goods for nonconformity; otherwise, such inspection will be made on return to Seller's storage facility. When such goods are confirmed or acquiesced in as nonconforming, Seller will ship conforming goods within 30 days of the notice of rejection unless Buyer earlier notifies Seller to forgo such shipment.
YOUR BILLING RIGHTS - KEEP THIS NOTICE FOR FUTURE USE This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
Important Information About Procedures for Opening a New Account To help the government fight the funding of terrorism and money laundering activities, Federal law requires all financial organizations to obtain, verify, and record information that identifies each person who opens an account. What this means for you: When you open an account, you are required to provide your name, residential address, date of birth, and identification number. We may require other information that will allow us to identify you.
Compliance with Xxxxx-Xxxxx and Related Act requirements All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.
Event of Loss with Respect to an Engine Upon the occurrence of an Event of Loss with respect to an Engine under circumstances in which there has not occurred an Event of Loss with respect to the Airframe, Lessee shall forthwith (and in any event, within fifteen days after such occurrence) give Lessor written notice thereof and shall, within one hundred twenty (120) days after the occurrence of such Event of Loss, convey or cause to be conveyed to Lessor, as replacement for the Engine with respect to which such Event of Loss occurred, title to an Acceptable Alternate Engine. Prior to or at the time of any such conveyance, Lessee, at its own expense, will (i) furnish Lessor with a warranty (as to title) xxxx of sale, in form and substance reasonably satisfactory to Lessor, with respect to such Acceptable Alternate Engine, (ii) cause a Lease Supplement and Trust Supplement to be duly executed by Lessee and to be filed for recording pursuant to the Transportation Code, or the applicable laws, rules and regulations of any other jurisdiction in which the Airframe may then be registered as permitted by Section 7(d) of the Participation Agreement, (iii) furnish Lessor with such evidence of compliance with the insurance provisions of Section 11 hereof with respect to such replacement engine as Lessor may reasonably request and furnish Lessor with copies of the documentation required to be provided by Lessee pursuant to Section 5.06 of the Trust Indenture, and Lessor will comply with the terms of the Trust Indenture and transfer to or at the direction of Lessee without recourse or warranty (except as to absence of Lessor Liens) all of Lessor's right, title and interest, if any, in and to (A) the Engine with respect to which such Event of Loss occurred and furnish to or at the direction of Lessee a xxxx of sale in form and substance reasonably satisfactory to Lessee, evidencing such transfer and (B) all claims, if any, against third parties, for damage to or loss of the Engine subject to such Event of Loss, and such Engine shall thereupon cease to be the Engine leased hereunder. For all purposes hereof, each such replacement engine shall, after such conveyance, be deemed part of the property leased hereunder, and shall be deemed an "Engine". No Event of Loss with respect to an Engine under the circumstances contemplated by the terms of this paragraph (b) shall result in any reduction in Basic Rent.
Sub-processing 11.1 The data importer shall not subcontract any of its processing operations performed on behalf of the data exporter under the Clauses without the prior written consent of the data exporter. Where the data importer subcontracts its obligations under the Clauses, with the consent of the data exporter, it shall do so only by way of a written agreement with the sub-processor which imposes the same obligations on the sub- processor as are imposed on the data importer under the Clauses. Where the sub-processor fails to fulfil its data protection obligations under such written agreement the data importer shall remain fully liable to the data exporter for the performance of the sub-processor’s obligations under such agreement. 11.2 The prior written contract between the data importer and the sub-processor shall also provide for a third-party beneficiary clause as laid down in Clause 3 for cases where the data subject is not able to bring the claim for compensation referred to in paragraph 1 of Clause 6 against the data exporter or the data importer because they have factually disappeared or have ceased to exist in law or have become insolvent and no successor entity has assumed the entire legal obligations of the data exporter or data importer by contract or by operation of law. Such third-party liability of the sub-processor shall be limited to its own processing operations under the Clauses. 11.3 The provisions relating to data protection aspects for sub-processing of the contract referred to in paragraph 1 shall be governed by the law of the Member State in which the data exporter is established, namely ........................................ 11.4 The data exporter shall keep a list of sub-processing agreements concluded under the Clauses and notified by the data importer pursuant to Clause 5(j), which shall be updated at least once a year. The list shall be available to the data exporter’s data protection supervisory authority.
Right to Refuse to Cross Picket Lines (a) All employees covered by this Agreement shall have the right to refuse to cross a picket line arising out of a dispute as defined in the appropriate legislation. Any employees failing to report for duty shall be considered to be absent without pay. (b) Failure to cross a picket line encountered in carrying out the Employer's business shall not be considered a violation of this Agreement nor shall it be grounds for disciplinary action.
Report of Contract Purchases Contractor shall furnish quarterly reports containing total sales for both State Agency and other Authorized User contract purchases no later than thirty (30) days after the close of each calendar quarter using the form set out in Appendix E, Report of Contract Purchases. In addition to Contractor direct sales, Contractor shall submit sales information for all resellers, dealers, distributors or other authorized distribution channels, where such contract sales are provided by other than the Contractor. A separate report shall be provided for each authorized distribution channel. Contractors shall verify if each alternate vendor is a NYS certified minority- or women- owned business (MBE or WBE, respectively). Contractors shall verify such status through the Empire State Development minority- and women-owned businesses database at: xxxxx://xx.xxxxxxxxxxxxxx.xxx/frontend/diversityusers.asp.. The required reporting elements will be provided by OGS. Reports will consist of an itemized report of all services provided and invoiced, shall be forwarded electronically in Excel (.xls or .xlsx) Format to the OGS Centralized Contract Administrator containing the information requested within the attachment workbook. If appropriate means are integrated into the NYS Statewide Financial System (SFS) Portal to allow direct input of the required reporting information, submission of the Report of Contract Purchases will migrate to that venue and the Contractor will follow the reporting format established within the SFS Vendor Portal. Announcement of any such new capability and reporting requirement will be made via a purchasing memorandum which will be forwarded to Contractor.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
