Delivery Defects and Warranty Claims Sample Clauses

Open Split View

Download

Share

Cite

Delivery Defects and Warranty Claims 

Sample 1Sample 2

Save

Copy

Related to Delivery Defects and Warranty Claims

• Warranty Claims 8.1 The Supplier shall be obliged to inspect the quantity and the quality of the goods before delivery. 8.2 We shall have no duty to inspect the goods nor to notify any detected defects within a specific time period. In any event, a warranty claim will be timely made if raised prior to the expiration of the warranty period set forth in sub- clause 8.7 hereof. 8.3 We are entitled to demand, at our discretion, that the Supplier either replace defective goods or remedy the defect. The Supplier may only refuse the form of supplementary performance we have chosen on the grounds of dispropor- tionate cost where such costs would exceed the value of the goods in defect-free condition. 8.4 The Supplier warrants that the supplied goods are free of any fault or defect, whether of design, workmanship or materials. 8.5 Where supplementary performance fails, we are entitled to withdraw from the contract according to applicable law. Supplementary performance shall be deemed to have failed after one unsuccessful attempt, provided that the type of product or defect does not indicate that we are required to accept a further attempt at supplementary perfor- xxxxx. 8.6 We are entitled to remedy defects ourselves or to have them remedied at the expense of the Supplier, or to under- take shortfall purchases, where exigency or particular urgency applies and it is no longer possible to notify the Sup- plier with a deadline because of such particular urgency. 8.7 The Supplier shall be liable for any breach of the warranties if, within 18 months after the delivery date, we give no- xxxx in writing to the Supplier of any defect in the goods which shall arise from faulty design, materials or xxxxxxx- ship. This warranty period starts upon delivery of the goods and shall be suspended while the Supplier attempts supplementary performance. With respect to replaced or repaired goods, a new warranty period shall commence upon delivery of the replaced or repaired goods. 8.8 We expressly reserve the right to claim damages under applicable law. Warranty disclaimers and/or limitations of li- ability on the part of the Supplier do not apply. The foregoing warranties shall be without prejudice to any other rights and remedies available to us. 8.9 The Supplier indemnifies and holds us harmless against third party claims in connection with defective, delayed or in other manners faulty delivery, including court and attorney fees.

• Manufacturer’s Warranty The Goods include the manufacturer’s standard limited parts warranty to replace defective parts covered under such warranty exclusive of labor. Labor is warranted by the Elevator Contractor for 90 days following installation. The manufacturer’s parts warranty may require that the Goods be maintained throughout the warranty period by an authorized manufacturer’s representative under a separate maintenance contract. Any warranty is conditioned on written notice to the Elevator Contractor within warranty period and contingent upon receipt of final payment to Elevator Contractor.

• Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.

• Product Warranty Seller provides general warranties of fitness and general warranties that the goods are free from defects, for 1 year from acceptance of the goods, except as may otherwise be set forth in the Description/Proposal, or other attached warranty.

• Seller’s Warranties 10.1 Each of the Sellers warrants to the Buyers, in the terms of the Warranties at the date of this Agreement. 10.2 The Warranties contained in paragraphs 1 to 5, 6.3, 8.3, 10.1, 10.5, 11.1, 13, 17.2 and 18 of Schedule 3 are made of the date hereof and are repeated as of the Completion Date by the Sellers; all other Warranties are made exclusively as of the date hereof. 10.3 The Warranties are qualified by matters fairly disclosed in the Disclosure Letter. In addition to any specific matter disclosed or deemed to be disclosed in accordance with the Disclosure Letter, if and to the extent that the Buyers or any of the directors, officers, employees and/or professional advisers of the Buyers respectively its Affiliates, to the extent they were involved in the investigation of the Company and its business, the evaluation of the Transaction and negotiation of this Agreement, was aware or had notice at any time before the signature of the Agreement of any information relating to the subject matter of the Warranties that could reasonably be expected to put the Buyer on notice of such breach in light of the circumstances, then the Warranties shall be qualified by such information. 10.4 Following the execution of this Agreement but prior to the Completion Date (i) with regard to Warranties listed in Clause 10.2 above the Sellers shall, and (ii) with regard to all other Warranties the Sellers may supplement or amend the Disclosure Letter to reflect matters or circumstances which have arisen after the date hereof. No supplement or amendment to the Disclosure Letter shall be deemed to cure any breach of any Warranty made as of the date of this Agreement or as of the Completion Date, as the case may be. Absent fraud or willful concealment, no failure to supplement or amend the Disclosure Letter in accordance with this Clause 10.4 shall, by itself, constitute a basis for any Claim. Acceptance of any amendment or supplement to the Disclosure Letter shall be without prejudice to the rights of the Buyers to claim for any breach of Warranty made as at the date of this Agreement or as of the Completion Date, as the case may be. 10.5 Where a Warranty is qualified by the expression “so far as the Sellers are aware”, that Warranty shall be deemed to refer to the actual knowledge of the Sellers, the Other Participants, Ixxx Xxxxx, Ixxxx Xxxxxxx, Vxxxxxxxxx Gnasevich, Vxxxxxxx Xxxxxxxx, Vxxxxxxx Xxxxxxxxxx, Txxxxxx Chabunuk, Exxxxxxxx Xxxxxxxx or Julija Didan, not having made any specific inquiries thereto. 10.6 Each of the Warranties shall be construed as a separate and independent warranty and (except where this Agreement provides otherwise) shall not be limited or restricted in its scope by reference to or inference from any other term of another Warranty or this Agreement. 10.7 The Buyers, together with their Representatives, have conducted their own independent investigation of the business of the Company. In entering into this Agreement, the Parties acknowledge that the Buyers are relying on the Warranties set forth in Schedule 3 of this Agreement, and the Buyers. 10.7.1 acknowledge that none of the Sellers, the Company or any of their respective shareholders or Representatives makes or has made any representation or warranty, either express or implied, as to the accuracy or completeness of any of the documents or other information provided or made available to the Buyers or any of its Representatives, 10.7.2 agree, to the fullest extent permitted by law, that none of the Sellers, the Company, any of their shareholders or Representatives shall have any liability or responsibility whatsoever to the Buyers or any of their Representatives on any basis based upon any information provided or made available, or statements made (including in materials furnished in the Data Room, in presentations by the Company’s management or otherwise), to the Buyers or any of their Representatives (or any omissions there from), except that the foregoing limitations shall not apply to any of the Sellers insofar as any such Seller makes the specific Warranties, set forth in Schedule 3 of this Agreement, subject always to the limitations and restrictions contained in Schedule 4.

• Manufacturer’s Warranties If a Lease Vehicle is covered by a Manufacturer’s warranty, the Lessee, during the Vehicle Term for such Lease Vehicle, shall have the right to make any claims under such warranty that the Lessor could make.

• Seller’s Representations and Warranties Seller represents and warrants to Purchaser that:

• REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.

• Title Warranty Assignor warrants that: a. Except as specifically set forth in the Purchase and Sale Agreement described in Article 10. below or under the contracts and agreements listed in Exhibit 1 to this Assignment, and further except as a consequence of the formation of a unit, neither Assignor nor any parent, subsidiary or affiliate of Assignor during their respective periods of ownership has (A) executed any deed, conveyance, assignment or other instrument as an assignor, grantor, sublessor or in another capacity or (B) has breached any obligation under any Lease that would (i) result in Assignee's being entitled to receive less than the net revenue interest for any Lease, well or unit set forth in Exhibit 1 of all oil and gas in, under, and that may be produced, saved and marketed from or attributable to such Lease, well or unit, or (ii) obligate Assignee to bear the costs and expenses relating to the maintenance, development and operation of such Lease, well or unit in an amount greater than the working interest for such Lease, well or unit set forth in Exhibit 1, unless the net revenue interest attributable to said working interest is increased by a proportionate or greater amount; and b. Except as specifically set forth in the Purchase and Sale Agreement described in Article 10. below or under the contracts and agreements listed in Exhibit 1 to this Assignment, the Assets are free of all liens, security interests and encumbrances; (the limited warranty set forth in subparagraphs (a) and (b) above shall hereinafter be referred to as the Special Limited Warranty ). Assignor shall convey the Assets with no warranty whatsoever other than the Special Limited Warranty, but with full substitution and subrogation to Assignee in and to all covenants, agreements, representations and warranties made by others heretofore given or made in connection with the Assets or any part thereof.

• Environmental Defects If Buyer determines that with respect to the Asset there exists an Environmental Condition (other than with respect to asbestos, asbestos containing materials, or NORM, and excluding any matter set forth on Schedule 6.10) (in each case, an “Environmental Defect”), then on or prior to the Defect Claim Date, Buyer may give Seller a written notice of such Environmental Defect that sets forth the information required by this Section 3.17 (an “Environmental Defect Notice”). For all purposes of this Agreement and notwithstanding anything herein to the contrary, Buyer shall be deemed to have waived any Environmental Defect that Buyer fails to timely and properly assert as an Environmental Defect by an Environmental Defect Notice received by Seller on or before the Defect Claim Date. To be effective, an Environmental Defect Notice must set forth (a) a clear description of the matter constituting the alleged Environmental Defect, (b) a description of each Asset (or portion thereof) affected by the alleged Environmental Defect, (c) the estimated proportionate share attributable to the Assets of the estimated Lowest Cost Response to eliminate the alleged Environmental Defect (the “Environmental Defect Amount”), and (d) supporting documents and reasonably necessary for Seller to verify the existence of the alleged Environmental Defect and the Environmental Defect Amount. Buyer shall furnish Seller, on or before the end of each calendar week prior to the Defect Claim Date, Environmental Defect Notices with respect to any Environmental Defects that any of Buyer’s or any of its Affiliate’s employees, representatives, attorneys, or other environmental personnel or contractors discover or become aware of during the preceding calendar week, which notice may be preliminary in nature and supplemented prior to the Defect Claim Date; provided that notwithstanding this sentence, any Environmental Defect Notice shall be deemed timely if received by Seller prior to the Defect Claim Date.