No Breach of Contract The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.
Termination for Breach of Contract 1. Except as provided in PSC-6, if CONTRACTOR fails to perform any of the provisions of this Contract or so fails to make progress as to endanger timely performance of this Contract, CITY may give CONTRACTOR written notice of the default. CITY’S default notice will indicate whether the default may be cured and the time period to cure the default to the sole satisfaction of CITY. Additionally, CITY’S default notice may offer CONTRACTOR an opportunity to provide CITY with a plan to cure the default, which shall be submitted to CITY within the time period allowed by CITY. At CITY’S sole discretion, CITY may accept or reject CONTRACTOR’S plan. If the default cannot be cured or if CONTRACTOR fails to cure within the period allowed by CITY, then CITY may terminate this Contract due to CONTRACTOR’S breach of this Contract.
Liability for Breach of Contract 1. Any Party who violates the provisions of this Agreement and makes all or part of this Agreement unenforceable, shall be liable for breach of contract and shall compensate the other Party for the losses caused thereby (including the litigation fees and attorney fees caused thereby). If both Parties breach this Agreement, each shall bear the corresponding responsibility according to the actual situations.
VIOLATION OF CONTRACT TERMS / BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer’s default, breach of contract, or violation of contract terms shall be paid by Engineer.
BREACH OF CONTRACT TERMS The State reserves its right to all administrative, contractual, or legal remedies, including but not limited to suspension or termination of this contract, in instances where the Contractor or any of its subcontractors violate or breach any contract term. If the Contractor or any of its subcontractors violate or breach any contract term, they shall be subject to such sanctions and penalties as may be appropriate. The duties and obligations imposed by the contract documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law.
Termination for Breach or Default If the County terminates the Contract for default or breach of any Contract provision or condition, then the termination will be immediate after notice of termination to the Contractor (unless the County provides for an opportunity to cure), and the Contractor will not be permitted to seek termination costs. Upon any termination pursuant to this section, the Contractor will be liable to the County for costs that the County must expend to complete the Work, including costs resulting from any related delays and from unsatisfactory or non-compliant work performed by the Contractor or its subcontractors. The County will deduct such costs from any amount due to the Contractor; or if the County does not owe the Contractor, the Contractor must promptly pay the costs within 15 days of a demand by the County. This section does not limit the County’s recovery of any other damages to which it is entitled by law. Except as otherwise directed by the County, the Contractor must stop work on the date of receipt the notice of the termination.
Breach of Covenant The Borrower breaches any material covenant or other term or condition of the Subscription Agreement or this Note in any material respect and such breach, if subject to cure, continues for a period of ten (10) business days after written notice to the Borrower from the Holder.
Defendant’s Breach of Plea Agreement If the defendant commits any crimes, violates any conditions of release, or violates any term of this plea agreement between the signing of this plea agreement and the date of sentencing, or fails to appear for sentencing, or if the defendant provides information to the Probation Office or the Court that is intentionally misleading, incomplete, or untruthful, or otherwise breaches this plea agreement, the United States will be released from its obligations under this agreement. The defendant, however, will remain bound by the terms of the agreement, and will not be allowed to withdraw his plea of guilty. The defendant also understands and agrees that in the event he violates this plea agreement, all statements made by him to law enforcement agents subsequent to the execution of this plea agreement, any testimony given by him before a grand jury or any tribunal or any leads from such statements or testimony shall be admissible against him in any and all criminal proceedings. The defendant waives any rights that he might assert under the United States Constitution, any statute, Rule 11(f) of the Federal Rules of Criminal Procedure, Rule 410 of the Federal Rules of Evidence, or any other federal rule that pertains to the admissibility of any statements made by him subsequent to this plea agreement.
