Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Execution of the Agreement The Company, the party executing this Agreement on behalf of the Company, and the Consultant, have the requisite corporate power and authority to enter into and carry out the terms and conditions of this Agreement, as well as all transactions contemplated hereunder. All corporate proceedings have been taken and all corporate authorizations and approvals have been secured which are necessary to authorize the execution, delivery and performance by the Company and the Consultant of this Agreement. This Agreement has been duly and validly executed and delivered by the Company and the Consultant and constitutes a valid and binding obligation, enforceable in accordance with the respective terms herein. Upon delivery of this Agreement, this Agreement, and the other agreements and exhibits referred to herein, will constitute the valid and binding obligations of Company, and will be enforceable in accordance with their respective terms. Delivery may take place via facsimile transmission.
Object and Scope of the Agreement The competent authorities of the Contracting Parties shall provide assistance through exchange of information that is foreseeably relevant to the administration and enforcement of the domestic laws of the Contracting Parties concerning taxes covered by this Agreement. Such information shall include information that is foreseeably relevant to the determination, assessment and collection of such taxes, the recovery and enforcement of tax claims, or the investigation or prosecution of tax matters. Information shall be exchanged in accordance with the provisions of this Agreement and shall be treated as confidential in the manner provided in Article 8. The rights and safeguards secured to persons by the laws or administrative practice of the requested Party remain applicable to the extent that they do not unduly prevent or delay effective exchange of information.
Formation of the Agreement 2.1 The Agreement is binding upon Supplier after accepting the Purchase Order as evidenced by acknowledgement, supply of Goods and/or performance of Services. Versuni expressly rejects Supplier’s general conditions of sale.
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a two bedroom service apartment unit, intermediate lot bearing postal address of No. A-20-10, Xxxxxx A, Residensi Southkey Mozek, Persiaran Southkey Utama, Kota Xxxxxxxx, 00000 Xxxxx Xxxxx, Xxxxx. RESERVE PRICE: The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM486,000.00 (RINGGIT MALAYSIA FOUR HUNDRED AND EIGHTY SIX THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Xxxxxxx’s Order in favour of UOBM for CHOONG LIP PONG or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S CHUA & PARTNERS, of Suite 8-12A-6, Xxxxx 00X, Xxxxxx Xxxxxxx, Xx. 0, Xxxxx Xxxx Xxxxxx, 00000 Xxxxx Xxxxxx. (Ref No.: MHH/UOB/A924/22/ChoongLipPong, Tel No. 00-0000 0000 / 00-0000 0000, Fax No.: 00-0000 0000) solicitors for the Assignee herein or the undermentioned Auctioneer. EHSAN AUCTIONEERS SDN. BHD. (Co. No. 617309-U) DATO’ HAJI XXXXX XXXXX BIN X.X. XXXX (D.I.M.P) Xxxxx X-00-0X, Xxxxx 00, Xxxxx X, Xxxxx Xxxxxx II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 & 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: XXXXX/UOB0477/CP(2) Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx OR Unit Xx. 0.00, 0xx Xxxxx, Xxxxxx XXX, Xx. 0, Xxxxx Xxxx Xxxx Xxxxx, 80000 Johor Bahru, Johor. H/P EN JO: 012-742 1763 (Marketing) PERISYTIHARAN JUALAN DALAM PERKARA MENGENAI PERJANJIAN PINJAMAN XXX SURATIKATAN PENYERAHAN HAK KEDUA-DUANYA BERTARIKH 06HB SEPTEMBER, 2016 ANTARA UNITED OVERSEAS BANK (MALAYSIA) BHD [No. Pendaftaran: 199301017069/271809-K] PIHAK PEMEGANG SERAHHAK/BANK XXX XXXXXX LIP PONG (NO K/P.: 820721-01-5979) PIHAK PEMINJAM / PIHAK PENYERAHHAK Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Pinjaman xxx Suratikatan Penyerahan Hak Kedua-duanya bertarikh 06hb September, 2016 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah. AKAN MENJUAL HARTANAH YANG DIHURAIKAN DI BAWAH SECARA LELONGAN AWAM SECARA ATAS TALIAN PADA 11HB JANUARI 2023BERSAMAAN HARI RABU, JAM 3.00 PETANG, XX XXXXX WEB XXX.XXXXXXXXXXXXXXXX.XXX Bakal pembida boleh mengemukakan bida untuk hartanah dalam talian melalui xxx.xxxxxxxxxxxxxxxx.xxx (Untuk pembidaan dalam talian, xxxx daftar sekurang-kurangnya satu (1) hari bekerja sebelum hari lelong untuk tujuan pendaftaran & pengesahan) NOTA: Xxxxx-xxxxx pembeli adalah dinasihatkan agar membuat perkara-perkara yang berikut sebelum jualan lelong:-
Operation of the Agreement A5.1 This Agreement is comprehensive and provides the terms and conditions of employment of employees covered by this Agreement, other than terms and conditions applying under applicable legislation.
Implementation of the Agreement Regulations of this Agreement relating to investments who investors of one Contracting Party realized before or after the entry into force of this Agreement, with what shall apply from the moment of its entry into force, provided that such investments conducted in accordance with the laws of that Party Contracting.
Purpose and Scope of the Agreement The scope of this Agreement is to set out the rules, terms and principles according to which each Partner shall commit himself on the following points: