Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:
Damage or Destruction of Premises (a) If the Premises or any part thereof shall be damaged by fire or other insured casualty, then, subject to the last paragraph of this Section, Landlord shall proceed with diligence, subject to then applicable statutes, building codes, zoning ordinances and regulations of any governmental authority, and at the expense of Landlord (but only to the extent of insurance proceeds made available to Landlord by any mortgagee of the Building and any ground lessor) to repair or cause to be repaired such damage (other than any Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and Tenant Work, which Tenant shall promptly commence, and proceed with diligence, to restore). All such repairs made necessary by any act or omission of Tenant shall be made at the Tenant’s expense to the extent that the cost of such repairs are less than the deductible amount in Landlord’s insurance policy. All repairs to and replacements of Tenant Property not deemed to be fixtures covered by Landlord’s property insurance and any Initial Tenant Improvements and Tenant Work shall be made by and at the expense of Tenant. The cost of any repairs performed under this Section by Landlord at Tenant’s request and at Tenant’s expense (including costs of design fees, financing, and charges for administration, overhead and construction management services by Landlord and Landlord’s contractor) shall constitute Additional Rent hereunder. If the Premises or any part thereof shall have been rendered unfit for use and occupation hereunder by reason of such damage, the Base Rent or a just and proportionate part thereof, according to the nature and extent to which the Premises shall have been so rendered unfit, shall be abated until the Premises (except as to Tenant Property, Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and any Tenant Work) shall have been restored as nearly as practicable to the condition in which they were immediately prior to such fire or other casualty; and that if and to the extent Landlord shall be unable to collect the insurance proceeds (including rent insurance proceeds) applicable to such damage because of some action or inaction on the part of Tenant, or the employees, licensees or invitees of Tenant, the cost of repairing such damage shall be paid by Tenant and there shall be no abatement of rent. Landlord shall not be liable for delays in the making of any such repairs that are due to government regulation, casualties, and strikes, unavailability of labor and materials, delays in obtaining insurance proceeds, and other causes beyond the reasonable control of Landlord, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. If the Premises or the Building are substantially damaged so as to prevent Tenant from using the Premises for the Permitted Use and the Premises have not been restored to the condition required pursuant to the terms of this Lease within two hundred and seventy (270) days following said casualty (or if such casualty occurs during the last 18 months of the term, within ninety (90) days after the date of such casualty), then Tenant may terminate this Lease upon thirty (30) days written notice to Landlord unless Landlord shall substantially complete such repair and restoration within such thirty (30) day period in which event Tenant’s termination shall be void and of no further force or effect.
Use of the Premises 8.1. To use the Premises only as a private residence for the occupation of the Tenant and his immediate family.
Destruction of Leased Premises In the event of damage or destruction of the Leased Premises by fire or any other casualty, this Lease shall not be terminated, but the Leased Premises shall be promptly and fully repaired and restored as the case may be by the Board to the extent of the Board’s insurance proceeds, provided such repair and or restoration returns the Leased Premises to substantially the same condition prior to such damage or destruction. Due allowance, however, shall be given for reasonable time required for adjustment and settlement of insurance claims, and for such other delays as may result from government restrictions, and controls on construction, if any, and for strikes, national emergencies and other conditions beyond the control of the Board. It is agreed that in the event of damage or destruction, this Lease shall continue in full force and effect, except for abatement of rent as provided herein. If the condition is such as to make the entire Leased Premises untenantable, then the rent which the County is obligated to pay hereunder shall xxxxx as of the date of the occurrence until the Leased Premises have been fully restored by the Board. Any unpaid or prepaid rent for the month in which said condition occurs shall be prorated and credited or paid to the appropriate Party. If the Leased Premises are partially damaged or destroyed, then during the period that the County is deprived of the use of the damaged portion of said Leased Premises, the County shall only be required to pay rent prorated to reflect that portion of the Leased Premises which continues to be tenantable and appropriate for the County’s use of the Leased Premises. The Board will proceed at its expense to the extent of its insurance proceeds, and as expeditiously as may be practicable to repair the damage. Notwithstanding any of the foregoing, the Board shall not be required to expend any funds, other than insurance proceeds, to repair the Leased Premises which have been damaged by casualty. In the event that the Board elects not to repair the damage because of a lack of insurance proceeds, or because the damages are so extensive to make repair economically unfeasible, in which event and at the Board’s sole option, the Board may terminate this Lease forthwith, by giving the County a written notice of its intention to terminate within sixty (60) days after the date of the casualty. No compensation, or claim, or diminution of rent other than as described above will be allowed or paid, by the Board, by reason of inconvenience, annoyance, or injury to business, arising from the necessity of repairing the Leased Premises or any portion of the Building of which they are a part.
DESTRUCTION OF PREMISES (A) If, during the term of this Lease, the Leased Premises are totally or partially destroyed by fire or the elements, so as to render the premises wholly unfit for occupancy, or make it impossible in the opinion of a licensed third party arbitrator knowledgeable in the child care business reasonably acceptable to Lessee and Lessor, for Lessee to conduct its business therein, then either Lessor or Lessee shall have the right to terminate this Lease from the date of such damage or destruction by giving written notice. The parties agree to use reasonable promptness to obtain the opinion of such licensed third party arbitrator. Upon the giving of such notice, Lessee shall immediately surrender the Leased Premises and all interest therein to Lessor, and in case of any such termination, Lessor may re-enter and repossess the Leased Premises and may dispossess all parties then in possession thereof. If not otherwise terminated, in the event the Leased Premises shall be repaired, restored, and rebuilt by Lessee with the use of insurance proceeds (which Lessor shall cooperate to make available), but otherwise at its own sole cost and expense, within one hundred eighty (180) days from the date of destruction (subject to force majuere as set forth in paragraph C hereof, then all rents payable by Lessee shall be abated during the period of repair and restoration to the extent Lessor shall be compensated by the proceeds of rents loss insurance. In no event shall Lessor be required to provide its own money for the repair or restoration of the Leased Premises other than the net proceeds of moneys received by it from any insurance policy or policies covering such loss or damages. Lessee shall be liable for repair of the Leased Premises with all reasonable speed, and the rents shall recommence on the date that the repairs are completed. Lessee shall be under no obligation to so repair during the last five (5) years of the term of the Lease, or as extended, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above.
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Rentable Area of the Premises The term "Rentable Area of the Premises" shall mean 29,227 square feet, which Landlord and Tenant have stipulated as the Rentable Area of the Premises. Tenant acknowledges that the Rentable Area of the Premises includes the usable area, without deduction for columns or projections, multiplied by a load factor to reflect a share of certain areas, which may include lobbies, corridors, mechanical, utility, janitorial, boiler and service rooms and closets, restrooms and other public, common and service areas of the Building.
The Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto, and an outline of the Project is set forth in Exhibit A-1 attached hereto. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises in the “Building,” as that term is defined in Section 1.1.2, below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the “Project,” as that term is defined in Section 1.1.2, below. Except as specifically set forth in this Lease, Tenant shall accept the Premises in its presently existing “as-is” condition and Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Tenant also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant’s business, except as specifically set forth in this Lease. However, notwithstanding the foregoing, Landlord agrees that base Building electrical, mechanical, heating, ventilation and air conditioning and plumbing systems located in the Premises shall be in good working order and the roof shall be water tight as of the date Landlord delivers possession of the Premises to Tenant. Except to the extent caused by the acts or omissions of Tenant or any Tenant Parties (as defined in Section 10.13 below) by any alterations or improvements performed by or on behalf of Tenant, if such systems and/or the roof are not in good working order as of the date possession of the Premises is delivered to Tenant and Tenant provides Landlord with notice of the same within ninety (90) days following the date Landlord delivers possession of the Premises to Tenant, Landlord shall be responsible for repairing or restoring the same at Landlord’s sole cost and expense. Subject to any repairs or restoration required by the immediately preceding sentence, the commencement of business operations from the Premises by Tenant shall presumptively establish that the Premises and the Building were at such time in good and sanitary order, condition and repair. For purposes of Section 1938 of the California Civil Code, Landlord hereby discloses to Tenant, and Tenant hereby acknowledges, that the Premises, the Building and the Project have not undergone inspection by a Certified Access Specialist (CASp).
Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
TENANT'S USE OF THE PREMISES Tenant shall use the Premises solely for the purposes set forth in Tenant's Use Clause. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall, by reason of the nature of Tenant's use or occupancy of the Premises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Insurance Services Office or any other organization performing a similar function. Tenant shall
